-
INVITATION TO BID
CONSTRUCTION CONTRACT
BID NUMBER: 11-01 Rebid OWNER:
Dulce Independent Schools
Sealed bid opening date: P.O. Box 547
April 19, 2011 2:00 P.M. Dulce, NM 87528
Dulce Independent Schools (575)759-2909
PROJECT: NEW HOUSING ON STADIUM DATE: March 29, 2011
BUILDING 3 DUPLEXES
DISTRICT PROJECT NO.: 11-01 Contact Name:
Naomi Vicenti, Business Manager
575-759-2909
DESIGN PROFESSIONAL OF RECORD:
Dan Detlefsen Design, LLC
BID OPENING ADDRESS:
DULCE INDEPENDENT SCHOOLS
P.O. BOX 547
113 HAWK DRIVE
DULCE, NM 87528
Telephone: (575)759-2909
Fax: (575) (759-3533)
IMPORTANT: BIDS MUST BE SUBMITTED IN A SEALED ENVELOPE WITH THE BID NUMBER AND OPENING DATE CLEARLY INDICATED ON THE BOTTOM LEFT HAND SIDE OF THE FRONT OF THE ENVELOPE.
SEALED BIDS WILL BE RECEIVED AT THE ABOVE SPECIFIED DATE, LOCAL TIME AND ADDRESS THEN PUBLICLY OPENED AT THE ABOVE SPECIFIED ADDRESS AND READ ALOUD. BIDS NOT RECEIVED BY THE ABOVE SPECIFIED DATE, LOCAL TIME AND AT THE LISTED ADDRESS PRIOR TO BID TIME, WILL NOT BE OPENED OR CONSIDERED. DELIVERY IS SOLELY THE RESPONSIBILITY OF THE BIDDER.
THIS BID IS SUBJECT TO THE REQUIREMENTS OF THE BIDDING DOCUMENTS AS DEFINED IN THE “INSTRUCTIONS TO BIDDERS,” SECTION 00100.
THE BID PROPOSAL FORM MUST BE ACCOMPANIED BY A SURETY BOND, SUBCONTRACTOR LISTING FORM, AND DOCUMENTS SPECIFIED IN THE “INSTRUCTIONS TO BIDDERS.”
Bidding Documents may be obtained at the office of the Business Manager upon payment of $ 25.00 for each complete set. CHECKS SHOULD BE MADE PAYABLE TO “OWNER” as listed on page 1 of this Invitation to Bid. Incomplete sets will not be issued. The successful Bidder will receive refund of his deposit, and any unsuccessful Bidder who returns the Bidding Documents in good and complete condition within fifteen (15) days of the Bid Opening will also receive refund of this deposit. No deposits will be returned after the fifteen-day period.
BIDDING DOCUMENTS MAY BE REVIEWED AT THE FOLLOWING LOCATIONS:
1. Dulce Independent Schools Business Manager
Bids shall be presented in the form of a total Base Bid proposal under a Lump Sum Contract plus any additive or deductive alternates that are selected by the Owner. A bid must be submitted on all bid items and alternates; segregated bids will not be accepted. Plans and specifications are available from the Business Manager.
NOTE: Base Bid price shall not include state gross receipts or local options taxes. Taxes will be included in the Contracted Amount at prevailing rates as a separate item to be paid by Owner.
In submitting this bid, each Bidder must satisfy all terms and conditions of the Bidding Documents. All work covered by this Invitation to Bid shall be in accordance with applicable state laws and, if bid amount is $60,000 or more, is subject to the minimum wage rate determination issued by the office of the Labor Commissioner for this project. If the bid amount of the contractor or any subcontractor exceeds $50,000, the contractor and/or subcontractor must comply with the registration requirements pursuant to the Public Works Minimum Wage Act.
Bid Security, if bid greater than $25,000, in the form of a surety bond executed by a surety company authorized to do business in the State of New Mexico in the amount of 5%_of the total bid, or the equivalent in cash by means of a cashier’s check or in a form satisfactory to the Owner, must accompany each bid in accordance with the Instructions to Bidders.
A 100% Performance Bond and a 100% Payment and Materials Bond executed by a surety company authorized to do business in the State of New Mexico shall be required from the successful Bidder prior to award of contract.
A completed Subcontractor Listing Form must accompany each bid.
Each subcontractor shall provide a performance and payment bond on a public works building project if the subcontractor’s contract (to the Contractor) for work to be performed on a project is one hundred twenty-five thousand dollars ($125,000) or more. Failure of a Subcontractor to provide required bond shall not subject the Owner to any increase in cost due to approved substitution of Subcontractor.
The Bidding Documents contain a time for completion of the work and further impose liquidated damages for failure to complete the work within that time period.
No Bidder may withdraw his bid for 45 days after the actual date of the opening thereof.
The Owner intends to award this Project to the lowest responsible Bidder. The Owner reserves the right to reject any and all bids, to waive technical irregularities, and to award the contract to the Bidder whose bid it deems to be in the best interest of the Owner.
Attention of the Bidder is particularly directed to the current requirements as to Resident Contractor’s Preference per Section 13-4-3 NMSA 1978. The provisions of Sections 13-4-1 through 13-4-4 NMSA 1978 are not applicable to projects receiving Federal aid or when the expenditure of Federal funds designated for a specific contract is involved.
Requests for approval of substitutions for “or equal” material or equipment, if allowed by the contract documents, must includes a detailed itemized comparison of the proposed substitution with the specified product and be submitted at least 10 days prior to the bid date in accordance with Paragraph
3.3 of the Instructions to Bidders.
Published April 7, 2011 in The Pagosa Springs SUN.
_________________________________________
COMBINED NOTICE - AMENDED - PUBLICATION
FORECLOSURE
SALE NO. 2011-008
To Whom It May Concern: This Notice is given with regard to the following described Deed of Trust:
On January 12, 2011, the undersigned Public Trustee caused the Notice of Election and Demand relating to the Deed of Trust described below to be recorded in the County of Archuleta records.
Original Grantor(s): Lonnie D. Patison and Lynda A. Patison
Original Beneficiary(ies): Mortgage Electronic Registration Systems, Inc., as nominee for American Mortgage Network, Inc., a Delaware Corporation
Current Holder of Evidence of Debt: BAC Home Loans Servicing, L.P.
Date of Deed of Trust: 3/24/2006
County of Recording: Archuleta
Recording Date of Deed of Trust: 3/29/2006
Recording Reception Number: 20602850
Original Principal Amount: $232,000.00
Outstanding Principal Balance: $255,503.41
Pursuant to CRS §38-38-101(4)(i), you are hereby notified that the covenants of the deed of trust have been violated as follows: failure to pay principal and interest when due together with all other payments provided for in the evidence of debt secured by the deed of trust and other violations thereof.
THE LIEN FORECLOSED MAY NOT BE A FIRST LIEN.
THE PROPERTY DESCRIBED HEREIN IS ALL OF THE PROPERTY CURRENTLY ENCUMBERED BY THE LIEN OF THE DEED OF TRUST.
SEE EXHIBIT A ATTACHED HERETO AND INCORPORATED HEREIN BY REFERENCE
EXHIBIT A
Lot 592X, being a consolidation of Lots 592 and 593, Lake Forest Estates, according to the plat thereof, recorded June 4, 1973 as Reception No. 77869, and as further defined and described in Resolution No. 2000-61, from the Board of County Commissioners, Archuleta County, Colorado, recorded July 11, 2000 as Reception No. 20006316, all in the Office of the Clerk and Recorder, Archuleta County, Colorado.
Also known by street and number as: 299 Stevens Circle, Pagosa Springs, CO 81147
NOTICE OF SALE
The current holder of the Evidence of Debt secured by the Deed of Trust, described herein, has filed Notice of Election and Demand for sale as provided by law and in said Deed of Trust.
THEREFORE, Notice Is Hereby Given that I will at public auction, at 10:00 A.M. on Thursday, 05/26/2011 the date to which the sale has been continued pursuant to C.R.S. 38-38-103(2)(a), at 449 San Juan St., Pagosa Springs, CO 81147, sell to the highest and best bidder for cash, the said real property and all interest of the said Grantor(s), Grantor(s)’ heirs and assigns therein, for the purpose of paying the indebtedness provided in said Evidence of Debt secured by the Deed of Trust, plus attorneys’ fees, the expenses of sale and other items allowed by law, and will issue to the purchaser a Certificate of Purchase, all as provided by law.
Amended First Publication: 4/7/2011
Amended Last Publication: 5/5/2011
Name of Publication: Pagosa Springs Sun
DATE: 3/30/2011
Betty A. Diller, Public Trustee in and for the County of Archuleta, State of Colorado
By: /s/ Betty A. Diller, Public Trustee
The name, address, telephone number and bar registration number of the attorney(s) representing the legal holder of the indebtedness is:
Cristel D. Shepherd #39351
Caren Jacobs Castle #11790
Barbara Bader #10394
Katharine E. Fisher #39230
Anthony L. Converse #40212
Jeffrey C. Gaston #40389
Deanne R. Stodden #33214
Jennifer C. Rogers #34682
Christopher T. Groen #39976
Jeffrey C. Gaston #40389
Reagan Larkin #42309
Elizabeth S. Marcus #16092
Britney Beall-Eder #64935
Kimberly L. Martinez #40351
Jason C. Hilliard #40856
Castle Stawiarski, LLC 999 18TH ST., #2201, DENVER, CO 80202 (303) 865-1400
The attorney above is acting as a debt collector and is attempting to collect a debt. Any information provided may be used for that purpose.
Attorney file #: 10-07484
©Colorado Public Trustees’ Association Revised 12/2009
Published April 7, 14, 21, 28 and May 5, 2011 in The Pagosa Springs SUN.
_________________________________________
COMBINED NOTICE - AMENDED - PUBLICATION
FORECLOSURE
SALE NO. 2011-013
To Whom It May Concern: This Notice is given with regard to the following described Deed of Trust:
On January 26, 2011, the undersigned Public Trustee caused the Notice of Election and Demand relating to the Deed of Trust described below to be recorded in the County of Archuleta records.
Original Grantor(s): Bill Manzanares and Lori J Manzanares
Original Beneficiary(ies): Mortgage Electronic Registration Systems, Inc., acting solely as nominee for HOMECOMINGS FINANCIAL, LLC (F/K/A HOMECOMINGS FINANCIAL NETWORK, INC.)
Current Holder of Evidence of Debt: Nationstar Mortgage LLC
Date of Deed of Trust: 1/1/2006
County of Recording: Archuleta
Recording Date of Deed of Trust: 1/6/2006
Recording Reception Number: 20611823
Original Principal Amount: $200,000.00
Outstanding Principal Balance: $189,408.47
Pursuant to CRS §38-38-101(4)(i), you are hereby notified that the covenants of the deed of trust have been violated as follows: failure to pay principal and interest when due together with all other payments provided for in the evidence of debt secured by the deed of trust and other violations thereof.
THE LIEN FORECLOSED MAY NOT BE A FIRST LIEN.
THE PROPERTY DESCRIBED HEREIN IS ALL OF THE PROPERTY CURRENTLY ENCUMBERED BY THE LIEN OF THE DEED OF TRUST.
LOT 5 OF BLOCK 1, HOLIDAY ACRES, UNIT NO. 1, ACCORDING TO THE PLAT THEREOF FILED FOR RECORD MAY 17, 1974 AS RECEPTION NO. 80067.
Also known by street and number as: 65 Clover Lane, Pagosa Springs, CO 81147
NOTICE OF SALE
The current holder of the Evidence of Debt secured by the Deed of Trust, described herein, has filed Notice of Election and Demand for sale as provided by law and in said Deed of Trust.
THEREFORE, Notice Is Hereby Given that I will at public auction, at 10:00 A.M. on Thursday, 06/02/2011 the date to which the sale has been continued pursuant to C.R.S. 38-38-103(2)(a), at 449 San Juan St., Pagosa Springs, CO 81147, sell to the highest and best bidder for cash, the said real property and all interest of the said Grantor(s), Grantor(s)’ heirs and assigns therein, for the purpose of paying the indebtedness provided in said Evidence of Debt secured by the Deed of Trust, plus attorneys’ fees, the expenses of sale and other items allowed by law, and will issue to the purchaser a Certificate of Purchase, all as provided by law.
Amended First Publication: 4/7/2011
Amended Last Publication: 5/5/2011
Name of Publication: Pagosa Springs Sun
DATE: 3/31/2011
Betty A. Diller, Public Trustee in and for the County of Archuleta, State of Colorado
By: /s/ Betty A. Diller, Public Trustee
The name, address, telephone number and bar registration number of the attorney(s) representing the legal holder of the indebtedness is:
Aronowitz & Mecklenburg, LLP 1199 Bannock Street, Denver, CO 80204 (303) 813-1177
The attorney above is acting as a debt collector and is attempting to collect a debt. Any information provided may be used for that purpose.
Attorney file #: 9696.01671
©Colorado Public Trustees’ Association Revised 12/2009
Published April 7, 14, 21, 28 and May 5, 2011 in The Pagosa Springs SUN.
_________________________________________
COMBINED NOTICE - PUBLICATION
CRS §38-38-103 FORECLOSURE
SALE NO. 2011-017
To Whom It May Concern: This Notice is given with regard to the following described Deed of Trust:
On January 28, 2011, the undersigned Public Trustee caused the Notice of Election and Demand relating to the Deed of Trust described below to be recorded in the County of Archuleta records.
Original Grantor(s): Sheila Nunez and Ronnie Nunez
Original Beneficiary(ies): Mortgage Electronic Registration Systems, Inc., as nominee for Acoustic Home Loans, LLC
Current Holder of Evidence of Debt: Deutsche Bank National Trust Company, As Trustee for the registered holders of GSAMP Trust 2006-SD2, Mortgage Pass-Through Certificates, Series 2006-SD2
Date of Deed of Trust: 9/13/2005
County of Recording: Archuleta
Recording Date of Deed of Trust: 9/14/2005
Recording Reception Number: 20509652
Original Principal Amount: $399,200.00
Outstanding Principal Balance: $402,705.81
Pursuant to CRS §38-38-101(4)(i), you are hereby notified that the covenants of the deed of trust have been violated as follows: failure to pay principal and interest when due together with all other payments provided for in the evidence of debt secured by the deed of trust and other violations thereof.
THE LIEN FORECLOSED MAY NOT BE A FIRST LIEN.
THE PROPERTY DESCRIBED HEREIN IS ALL OF THE PROPERTY CURRENTLY ENCUMBERED BY THE LIEN OF THE DEED OF TRUST.
LOT 55, PAGOSA MEADOWS, ACCORDING TO THE PLAT THEREOF FILED JUNE 1, 1970, AS RECEPTION NO. 73220, IN THE OFFICE OF THE CLERK AND RECORDER, ARCHULETA COUNTY, COLORADO
Also known by street and number as: 194 Paciente Place, Pagosa Springs, CO 81147
NOTICE OF SALE
The current holder of the Evidence of Debt secured by the Deed of Trust, described herein, has filed Notice of Election and Demand for sale as provided by law and in said Deed of Trust.
THEREFORE, Notice Is Hereby Given that I will at public auction, at 10:00 A.M. on Thursday, 06/02/2011, at 449 San Juan St., Pagosa Springs, CO 81147, sell to the highest and best bidder for cash, the said real property and all interest of the said Grantor(s), Grantor(s)’ heirs and assigns therein, for the purpose of paying the indebtedness provided in said Evidence of Debt secured by the Deed of Trust, plus attorneys’ fees, the expenses of sale and other items allowed by law, and will issue to the purchaser a Certificate of Purchase, all as provided by law.
First Publication: 4/7/2011
Last Publication: 5/5/2011
Name of Publication: Pagosa Springs Sun
DATE: 01/28/2011
Betty A. Diller, Public Trustee in and for the County of Archuleta, State of Colorado
By: /s/ Betty A. Diller, Public Trustee
The name, address, telephone number and bar registration number of the attorney(s) representing the legal holder of the indebtedness is:
Edward P. O’Brien #11572
Martin H. Shore #1800
David A. Shore #19973
Scott D. Toebben #19011
Hellerstein and Shore PC PO BOX 5637, DENVER, CO 80217 (303) 573-1080
The attorney above is acting as a debt collector and is attempting to collect a debt. Any information provided may be used for that purpose.
Attorney file #: 10-00446SH
©Colorado Public Trustees’ Association Revised 12/2009
Published April 7, 14, 21, 28 and May 5, 2011 in The Pagosa Springs SUN.
_________________________________________
COMBINED NOTICE - PUBLICATION
CRS §38-38-103 FORECLOSURE
SALE NO. 2011-019
To Whom It May Concern: This Notice is given with regard to the following described Deed of Trust:
On February 2, 2011, the undersigned Public Trustee caused the Notice of Election and Demand relating to the Deed of Trust described below to be recorded in the County of Archuleta records.
Original Grantor(s): Pagosa Partners, II, Inc. (as to Parcel 1) Robert J. Ralis (as to Parcel 2)
Original Beneficiary(ies): Community Banks of Colorado
Current Holder of Evidence of Debt: Community Banks of Colorado
Date of Deed of Trust: 11/24/2009
County of Recording: Archuleta
Recording Date of Deed of Trust: 11/30/2009
Recording Reception Number: 20909455
Original Principal Amount: $130,000.00
Outstanding Principal Balance: $130,000.00
Pursuant to CRS §38-38-101(4)(i), you are hereby notified that the covenants of the deed of trust have been violated as follows: failure to pay principal and interest when due together with all other payments provided for in the evidence of debt secured by the deed of trust and other violations thereof.
THE LIEN FORECLOSED MAY NOT BE A FIRST LIEN.
THE PROPERTY DESCRIBED HEREIN IS ALL OF THE PROPERTY CURRENTLY ENCUMBERED BY THE LIEN OF THE DEED OF TRUST.
Parcel 1:
Lot 2, Block 8, Aspen Village Phase 2 Planned Unit Development, according to the plat thereof filed October 13, 2005, as Reception No. 20510843, in the office of the Clerk and Recorder, Archuleta County, Colorado.
Parcel 2:
Lot 45, Martinez Mountain Estates Unit Two according to the plat thereof filed March 31, 1980, as Reception No. 99072, in the office of the Clerk and Recorder, Archuleta County, Colorado.
Also known by street and number as: 2839 Cornerstone Drive, Pagosa Springs, CO 81147
NOTICE OF SALE
The current holder of the Evidence of Debt secured by the Deed of Trust, described herein, has filed Notice of Election and Demand for sale as provided by law and in said Deed of Trust.
THEREFORE, Notice Is Hereby Given that I will at public auction, at 10:00 A.M. on Thursday, 06/02/2011, at 449 San Juan St., Pagosa Springs, CO 81147, sell to the highest and best bidder for cash, the said real property and all interest of the said Grantor(s), Grantor(s)’ heirs and assigns therein, for the purpose of paying the indebtedness provided in said Evidence of Debt secured by the Deed of Trust, plus attorneys’ fees, the expenses of sale and other items allowed by law, and will issue to the purchaser a Certificate of Purchase, all as provided by law.
First Publication: 4/7/2011
Last Publication: 5/5/2011
Name of Publication: Pagosa Springs Sun
DATE: 02/02/2011
Betty A. Diller, Public Trustee in and for the County of Archuleta, State of Colorado
By: /s/ Betty A. Diller, Public Trustee
The name, address, telephone number and bar registration number of the attorney(s) representing the legal holder of the indebtedness is:
Jones & Keller 5613 DTC Parkway. Suite 970, Greenwood Village, CO 80111 (303) 376-8400
The attorney above is acting as a debt collector and is attempting to collect a debt. Any information provided may be used for that purpose.
Attorney file #: 12179-340
©Colorado Public Trustees’ Association Revised 12/2009
Published April 7, 14, 21, 28 and May 5, 2011 in The Pagosa Springs SUN.
_________________________________________
District Court, Archuleta County, State of Colorado
Court Address: PO Box 148, 449 San Juan St.
Pagosa Springs, CO 81147
EAGLE’S LOFT PROPERTY OWNERS ASSOCIATION, INC.
Plaintiffs,
vs.
VERNON L. HOPSON AND BONITA R. HOPSON, TRUSTEES OF THE VERNON L. HOPSON AND BONITA R. HOPSON REVOCABLE TRUST DATED 2-24-1996 and All Unknown Persons Who Claim Any Interest In The Subject Matter Of This Action,
Defendants.
Attorney for Plaintiffs:
Larry W. Holthus
PO Box 1737
Pagosa Springs, CO 81147
Phone Number: (970) 264-4196
FAX Number: (970) 264-4197
Atty. Reg. #: 10535
Case Number: 11CV13
SUMMONS BY PUBLICATION
THE PEOPLE OF THE STATE OF COLORADO TO THE ABOVE NAMED DEFENDANTS:
You are hereby summoned and required to appear and defend against the claims of the Complaint filed with the Court in this action, by filing with the Clerk of this Court, an Answer or other response. You are required to file your Answer or other response within thirty (30) days after the date of the last publication. A copy of the Complaint may be obtained from the Clerk of the Court.
If you fail to file your Answer or other response to the Complaint in writing within thirty (30) days after the date of the last publication, judgment by default may be rendered against you by the Court for the relief demanded in the Complaint without further notice.
This is an action to quiet title to:
Unit Number 20, Building Number 20, Unit Week Number 20, in “EAGLE’S LOFT – Phase Three, as Reception No. 130203 and in accordance with and as limited and defined by the Declaration of Individual and/or Interval Ownership, recorded under Reception Number 117700 in Book 200 at Page 834 et seq and amendments and supplements thereto in the Office of the County Clerk and Recorder in and for Archuleta County, Colorado.
Dated this 21st day of March, 2011.
/s/ Larry W. Holthus
Larry W. Holthus
Published April 7, 14, 21, 28 and May 5, 2011 in The Pagosa Springs SUN.
_________________________________________
District Court, Archuleta County, State of Colorado
Court Address: PO Box 148, 449 San Juan St.
Pagosa Springs, CO 81147
PTARMIGAN PROPERTY OWNERS ASSOCIATION, INC.
Plaintiffs,
vs.
VACATION SOLUTIONS, LLC, A NEVADA LIMITED LIABILITY COMPANY and All Unknown Persons Who Claim Any Interest in the Subject Matter of This Action,
Defendants.
Attorney for Plaintiffs:
Larry W. Holthus
PO Box 1737
Pagosa Springs, CO 81147
Phone Number: (970) 264-4196
FAX Number: (970) 264-4197
Atty. Reg. #: 10535
Case Number: 11 CV83
SUMMONS BY PUBLICATION
THE PEOPLE OF THE STATE OF COLORADO TO THE ABOVE NAMED DEFENDANTS:
You are hereby summoned and required to appear and defend against the claims of the Complaint filed with the Court in this action, by filing with the Clerk of this Court, an Answer or other response. You are required to file your Answer or other response within thirty (30) days after the date of the last publication. A copy of the Complaint may be obtained from the Clerk of the Court.
If you fail to file your Answer or other response to the Complaint in writing within thirty (30) days after the date of the last publication, judgment by default may be rendered against you by the Court for the relief demanded in the Complaint without further notice.
This is an action to quiet title to:
Unit Number 7202, Building Number 1, Unit Week Number 27, in “Ptarmigan Townhouses Phase as recorded under Reception No. 153256 subject to Declaration of Individual and/or Interval Ownership for Ptarmigan Townhouses recorded under Reception Number 153557 and amendments and supplements thereto in the Office of the County Clerk and Recorder in and for Archuleta County, Colorado.
Dated this 25TH day of March, 2011.
/s/ Larry W. Holthus
Larry W. Holthus
Published April 7, 14, 21, 28 and May 5, 2011 in The Pagosa Springs SUN.
_________________________________________
The Town of Pagosa Springs is soliciting proposals for the design and fabrication for light pole banners for Pagosa Springs, Colorado. A Request for Proposal and scope of work may be obtained at Town Hall at 551 Hot Springs Blvd or online at www.townofpagosasprings.com. Please submit your proposal to the Pagosa Springs Planning Department, PO Box 1859, 551 Hot Springs Blvd, Pagosa Springs, Colorado 81147 by 3:00 pm on Friday April 22nd, 2011.
Published April 7 and 14, 2011 in The Pagosa Springs SUN.
_________________________________________
INVITATION TO BID
Separate sealed BIDS for Lewis Street Reconstruction (1st St. to 4th St.) will be received by the Town of Pagosa Springs at the office of Davis Engineering Service, Inc. located at 188 South 8th Street, P.O. Box 1208, Pagosa Springs, Colorado 81147, until 2:00 P.M. on April 28, 2011, and then at said office publicly opened and read aloud.
The project consists of reconstruction of 3 blocks of Lewis Street (approximately 2,600 linear feet) and includes excavation and removal of approximately 794 square yards of existing curb and gutter, 480 square yards of sidewalk, 11,755 square yards of asphalt, and 3,197 cubic yards of additional street material. Also included is construction of approximately 2,100 linear feet of storm sewer, 5,050 linear feet of curb and gutter (192 linear feet heated), 17,000 square feet of concrete sidewalk (5,500 square feet heated), 2,825 tons of asphalt paving, all with associated gravel placement (total of 3,537 cubic yards), and construction of approximately 50 access modifications along the street including gravel, asphalt, and concrete driveways, and concrete stairs and additional concrete sidewalks. The project described above is the complete project. It is possible that the bid schedule will be set up to allow for phasing of the project and/or with additive items that may/may not be awarded based upon the Town of Pagosa Springs’ budget and bid prices received.
Copies of the CONTRACT DOCUMENTS and PLANS may be obtained on or after April 11, 2011, at the office of Davis Engineering Service, Inc. located at the address mentioned above, upon payment of $100.00 for each set. No refund will be made for returned copies.
The Town of Pagosa Springs has a local preference policy which may be enforced in awarding this project. The policy will be available for review at the Town of Pagosa Springs Town Hall located at 551 Hot Springs Blvd., Pagosa Springs, CO 81147.
A mandatory pre-bid conference and inspection trip for prospective Bidders will be held at the office of Davis Engineering Service, Inc. (phone number (970) 264-5055), located at the address mentioned above, at 2:00 P.M. April 19, 2011. It is anticipated that the project construction will begin the end of May 2011.
Date: March 31, 2011
Published April 7, 14 and 21, 2011 in The Pagosa Springs SUN.
_________________________________________
ARCHULETA COUNTY COMBINED COURT
P.O. BOX 148
PAGOSA SPRINGS, CO 81147
Case No. 11C80
PUBLIC NOTICE OF PETITION
FOR CHANGE OF NAME
Public Notice is given on March 25, 2011, that a Petition for a Change of Name of a Minor Child has been filed with the Archuleta County Court.
The Petition requests that the name of Ayden Manuel Castillo be changed to Ayden Manuel Montoya.
/s/ Debbie Tully
Clerk of Court
Published April 7, 14 and 21, 2011 in The Pagosa Springs SUN.
_________________________________________
NOTICE TO CREDITORS
Estate of Christopher Allison McMillan, Deceased
Case No. 11 PR 5
All persons having claims against the above-named estate are required to present them to the Personal Representative or to the District Court of Archuleta County, Colorado on or before August 15, 2011, or the claims may be forever barred.
Rebecca McMillan
PO Box 651
Rosamond, CA 935602
Published April 7, 14 and 21, 2011 in The Pagosa Springs SUN.
_________________________________________
ARCHULETA COUNTY COMBINED COURT
P.O. BOX 148
PAGOSA SPRINGS, CO 81147
Case No. 11C80
In the Matter of the Petition of:
Parent/Petitioner: Stephanie Montoya for
Minor Child: Ayden Manuel Castillo
to Change the Child’s Name to: Ayden Manuel Montoya
NOTICE TO NON-CUSTODIAL PARENT
BY PUBLICATION
Notice to: Richard Castillo, non-custodial parent.
Notice is given that a hearing is scheduled as follows:
Date: May 27, 2011
Time: 1:30 p.m.
Location: 449 San Juan Street
Pagosa Springs, Colorado
for the purpose of requesting a change of name for Ayden Manuel Castillo.
At this hearing the Court may enter an order changing the name of the minor child.
To support or voice objection to the proposed name change, you must appear at the hearing.
Date: 3/21/2011
/s/ Stephanie Montoya
Stephanie Montoya
PO Box 181
Pagosa Springs, CO 81147
Published April 7, 14, 21, 28 and May 5, 2011 in The Pagosa Springs SUN.
_________________________________________
District Court, Archuleta County, State of Colorado
Court Address: 449 San Juan Street, P.O. Box 148
Pagosa Springs, Colorado 81147
Telephone No.: (970) 264-2400
MOUNTAIN MEADOWS PROPERTY OWNERS ASSOCIATION, INC.
Plaintiff
v.
BRUCE BROWN, SHARYLL BROWN and All Unknown Persons Who Claim Any Interest In The Subject Matter Of This Action,
Defendant.
Attorney for Plaintiff:
Name: Larry W. Holthus
Address: P.O. Box 1737
Pagosa Springs, Colorado 81147
Telephone No.: (970) 264-4196
Facsimile No.: (970) 264-4197
Atty. Reg. No.: 10535
Case Number: 10CV234
SHERIFF’S COMBINED NOTICE OF SALE, RIGHT TO CURE AND RIGHT TO REDEEM
TO WHOM IT MAY CONCERN:
This is to advise you that the above-captioned action is pending. A Judgment and Decree for Judicial Foreclosure has been entered in this action concerning an assessment lien by the plaintiff Mountain Meadows Property Owners Association, Inc. pursuant to the Colorado Common Interest Ownership Act, Colorado Revised Statutes, §3-33.3-316(2)(a), and the Plaintiff’s Property Owners Association Declaration for Mountain Meadows Property Owners Association, Inc. of (said) Assessment Lien being recorded on July 27, 2010 at Reception No. 21004955, in the office of the Clerk and Recorders Office of Archuleta County, Colorado (the “Assessment Lien”).
The real property which is the subject matter of this litigation, which is the property subject to the Assessment Lien, is situation in Archuleta County, and is described as follows, to-wit:
One (1) Red Unit Week as said Week is defined in the Declaration of Interval Ownership for Mountain Meadows recorded under Reception No. 137132, and amendments and supplements thereto in Building Number One of Mountain Meadows Townhomes-Phase One filed for record under Reception No 137131. Together with a right of ingress and egress over the existing road to Lakeside Drive.
The Plaintiff named above is the judgment creditor in this action and the lienor of the property pursuant to the Colorado Common Interest Ownership Act, Colorado revised Statutes, §33-33.3-316(2)(a), and the Plaintiff’s Property Owners Association Declaration for Mountain Meadows Property Owners Association. As of March 13, 2011, the outstanding balance due and owing on such judgment is $1,822.01
I shall offer for public sale to the highest bidder, for case, at public auction, all the right, title and interest of the defendants in said property on July 13, 2011 at 10:00 a.m. at the Archuleta County Sheriff’s Office, 449 San Juan St., Pagosa Springs, CO 81147.
NOTE: THE LIEN BEING FORECLOSED MAY NOT BE A FIRST LIEN.
Attached hereto are copies of certain Colorado statutes that my vitally affect your property rights in relation to this proceeding. Said proceeding may result in the loss of property in which you have an interest. You may wish to seek the advice of your own private attorney concerning your rights in relation to this foreclosure proceeding.
C.R.S. §38-38-103(4)(a)(II): A notice of intent to cure filed pursuant to section 38-38-104 shall be filed with the officer at least fifteen calendar days prior to the first scheduled sale date or any date to which the sale is continued;
C.R.S. §38-38-103(4)(a)(III): A notice of intent to redeem filed pursuant to section 38-38-302 shall be filed with the officer no later than eight business days after the sale;
INTENT to cure and redeem, as provided by the aforementioned laws, must be directed to or conducted at the Office of the Sheriff for the County of Archuleta, Front Office, 449 San Juan Street, Pagosa Springs, CO 81147.
Dated at Archuleta County, Colorado, this 1st day of April, 2011.
/s/ Peter L. Gonzalez
Peter L. Gonzalez
Sheriff, Archuleta County, Colorado
Sale Date: July 13, 2011 at 10:a.m.
BIDDERS ARE REQUIRED TO HAVE CASH OR CERTIFIED FUNDS TO COVER THEIR HIGHEST BID AT THE TIME OF THE SALE. CERTIFIED FUNDS ARE PAYABLE TO THE REGISTRY OF THE ARCHULETA COUNTY DISTRICT COURT.
Colorado Statutes attached: Colorado Revised Statutes §38-37-108, 38-38-103, 38-38-104,38-38-301,38-38-304,38-38-305, and 38-38-306.
Published April 7, 14, 21, 28 and May 5, 2011 in The Pagosa Springs SUN.
_________________________________________
District Court, Archuleta County, State of Colorado
Court Address: 449 San Juan Street, P.O. Box 148
Pagosa Springs, Colorado 81147
Telephone No.: (970) 264-2400
MOUNTAIN MEADOWS PROPERTY OWNERS ASSOCIATION, INC.
Plaintiff
v.
WILLIAM WERNER and All Unknown Persons Who Claim Any Interest In The Subject Matter Of This Action,
Defendant.
Attorney for Plaintiff:
Name: Larry W. Holthus
Address: P.O. Box 1737
Pagosa Springs, Colorado 81147
Telephone No.: (970) 264-4196
Facsimile No.: (970) 264-4197
Atty. Reg. No.: 10535
Case Number: 10CV233
SHERIFF’S COMBINED NOTICE OF SALE, RIGHT TO CURE AND RIGHT TO REDEEM
TO WHOM IT MAY CONCERN:
This is to advise you that the above-captioned action is pending. A Judgment and Decree for Judicial Foreclosure has been entered in this action concerning an assessment lien by the plaintiff Mountain Meadows Property Owners Association, Inc. pursuant to the Colorado Common Interest Ownership Act, Colorado Revised Statutes, §3-33.3-316(2)(a), and the Plaintiff’s Property Owners Association Declaration for Mountain Meadows Property Owners Association, Inc. of (said) Assessment Lien being recorded on July 27, 2010 at Reception No. 21004964, in the office of the Clerk and Recorders Office of Archuleta County, Colorado (the “Assessment Lien”).
The real property which is the subject matter of this litigation, which is the property subject to the Assessment Lien, is situation in Archuleta County, and is described as follows, to-wit:
Mountain Meadows Townhomes, One (1) Spring Unit Week as said Week is numbered and defined in the Declaration of Interval Ownership for Mountain Meadows recorded under Reception No. 137132, and amendments and supplements thereto, as identified in Unite Numbers 7601 through 7608 of “Mountain meadows Townhomes-Phase Two” filed for record under Reception No. 20209311. Together with a right of ingress and egress over the existing road to Lakeside Drive.
The Plaintiff named above is the judgment creditor in this action and the lienor of the property pursuant to the Colorado Common Interest Ownership Act, Colorado revised Statutes, §33-33.3-316(2)(a), and the Plaintiff’s Property Owners Association Declaration for Mountain Meadows Property Owners Association. As of March 13, 2011, the outstanding balance due and owing on such judgment is $2,894.37.
I shall offer for public sale to the highest bidder, for case, at public auction, all the right, title and interest of the defendants in said property on July 13, 2011 at 10:00 a.m. at the Archuleta County Sheriff’s Office, 449 San Juan St., Pagosa Springs, CO 81147.
NOTE: THE LIEN BEING FORECLOSED MAY NOT BE A FIRST LIEN.
Attached hereto are copies of certain Colorado statutes that my vitally affect your property rights in relation to this proceeding. Said proceeding may result in the loss of property in which you have an interest. You may wish to seek the advice of your own private attorney concerning your rights in relation to this foreclosure proceeding.
C.R.S. §38-38-103(4)(a)(II): A notice of intent to cure filed pursuant to section 38-38-104 shall be filed with the officer at least fifteen calendar days prior to the first scheduled sale date or any date to which the sale is continued;
C.R.S. §38-38-103(4)(a)(III): A notice of intent to redeem filed pursuant to section 38-38-302 shall be filed with the officer no later than eight business days after the sale;
INTENT to cure and redeem, as provided by the aforementioned laws, must be directed to or conducted at the Office of the Sheriff for the County of Archuleta, Front Office, 449 San Juan Street, Pagosa Springs, CO 81147.
Dated at Archuleta County, Colorado, this 1st day of April, 2011.
/s/ Peter L. Gonzalez
Peter L. Gonzalez
Sheriff, Archuleta County, Colorado
Sale Date: July 13, 2011 at 10:00 a.m.
BIDDERS ARE REQUIRED TO HAVE CASH OR CERTIFIED FUNDS TO COVER THEIR HIGHEST BID AT THE TIME OF THE SALE. CERTIFIED FUNDS ARE PAYABLE TO THE REGISTRY OF THE ARCHULETA COUNTY DISTRICT COURT.
Colorado Statutes attached: Colorado Revised Statutes §38-37-108, 38-38-103, 38-38-104,38-38-301,38-38-304,38-38-305, and 38-38-306.
Published April 7, 14, 21, 28 and May 5, 2011 in The Pagosa Springs SUN.
_________________________________________
COMBINED NOTICE - PUBLICATION
CRS §38-38-103 FORECLOSURE
SALE NO. 2011-013
To Whom It May Concern: This Notice is given with regard to the following described Deed of Trust:
On January 26, 2011, the undersigned Public Trustee caused the Notice of Election and Demand relating to the Deed of Trust described below to be recorded in the County of Archuleta records.
Original Grantor(s): Bill Manzanares and Lori J Manzanares
Original Beneficiary(ies): Mortgage Electronic Registration Systems, Inc., acting solely as nominee for HOMECOMINGS FINANCIAL, LLC (F/K/A HOMECOMINGS FINANCIAL NETWORK, INC.)
Current Holder of Evidence of Debt: Nationstar Mortgage LLC
Date of Deed of Trust: 1/1/2006
County of Recording: Archuleta
Recording Date of Deed of Trust: 1/6/2006
Recording Reception Number: 20611823
Original Principal Amount: $200,000.00
Outstanding Principal Balance: $189,408.47
Pursuant to CRS §38-38-101(4)(i), you are hereby notified that the covenants of the deed of trust have been violated as follows: failure to pay principal and interest when due together with all other payments provided for in the evidence of debt secured by the deed of trust and other violations thereof.
THE LIEN FORECLOSED MAY NOT BE A FIRST LIEN.
THE PROPERTY DESCRIBED HEREIN IS ALL OF THE PROPERTY CURRENTLY ENCUMBERED BY THE LIEN OF THE DEED OF TRUST.
LOT 5 OF BLOCK 1, HOLIDAY ACRES, UNIT NO. 1, ACCORDING TO THE PLAT THEREOF FILED FOR RECORD MAY 17, 1974 AS RECEPTION NO. 80067.
Also known by street and number as: 65 Clover Lane, Pagosa Springs, CO 81147
NOTICE OF SALE
The current holder of the Evidence of Debt secured by the Deed of Trust, described herein, has filed Notice of Election and Demand for sale as provided by law and in said Deed of Trust.
THEREFORE, Notice Is Hereby Given that I will at public auction, at 10:00 A.M. on Thursday, 05/26/2011, at 449 San Juan St., Pagosa Springs, CO 81147, sell to the highest and best bidder for cash, the said real property and all interest of the said Grantor(s), Grantor(s)’ heirs and assigns therein, for the purpose of paying the indebtedness provided in said Evidence of Debt secured by the Deed of Trust, plus attorneys’ fees, the expenses of sale and other items allowed by law, and will issue to the purchaser a Certificate of Purchase, all as provided by law.
First Publication: 3/31/2011
Last Publication: 4/28/2011
Name of Publication: Pagosa Springs Sun
DATE: 01/26/2011
Betty A. Diller, Public Trustee in and for the County of Archuleta, State of Colorado
By: /s/ Betty A. Diller, Public Trustee
The name, address, telephone number and bar registration number of the attorney(s) representing the legal holder of the indebtedness is:
Aronowitz & Mecklenburg, LLP 1199 Bannock Street, Denver, CO 80204 (303) 813-1177
The attorney above is acting as a debt collector and is attempting to collect a debt. Any information provided may be used for that purpose.
Attorney file #: 9696.01671
©Colorado Public Trustees’ Association Revised 12/2009
Published March 31, April 7, 14, 21 and 28, 2011 in The Pagosa Springs SUN.
_________________________________________
COMBINED NOTICE - PUBLICATION
CRS §38-38-103 FORECLOSURE
SALE NO. 2011-014
To Whom It May Concern: This Notice is given with regard to the following described Deed of Trust:
On January 26, 2011, the undersigned Public Trustee caused the Notice of Election and Demand relating to the Deed of Trust described below to be recorded in the County of Archuleta records.
Original Grantor(s): Darlene Rae Peterson
Original Beneficiary(ies): Freestand Financial Holding Corp.
Current Holder of Evidence of Debt: US BANK NATIONAL ASSOCIATION
Date of Deed of Trust: 3/10/2006
County of Recording: Archuleta
Recording Date of Deed of Trust: 3/16/2006
Recording Reception Number: 20602542
Original Principal Amount: $350,000.00
Outstanding Principal Balance: $349,985.38
Pursuant to CRS §38-38-101(4)(i), you are hereby notified that the covenants of the deed of trust have been violated as follows: failure to pay principal and interest when due together with all other payments provided for in the evidence of debt secured by the deed of trust and other violations thereof.
THE LIEN FORECLOSED MAY NOT BE A FIRST LIEN.
THE PROPERTY DESCRIBED HEREIN IS ALL OF THE PROPERTY CURRENTLY ENCUMBERED BY THE LIEN OF THE DEED OF TRUST.
SEE EXHIBIT A ATTACHED HERETO AND INCORPORATED HEREIN BY REFERENCE
EXHIBIT A
LOT 8X, BEING A CONSOLIDATION OF LOTS 4 AND 8, PAGOSA HILLS SUBDIVISION NO. 4, BEING A RE-PLAT OF LOTS 1-4, 8-10, 17, 19 AND 32-36, ACCORDING TO THE PLAT THEREOF FILED FOR RECORD JUNE 21, 1977 AS RECEPTION NO. 88397 AND PURSUANT TO A RESOLUTION APPROVING THE CONSOLIDATION OF CERTAIN LOTS IN ARCHULETA COUNTY, COLORADO, RESOLUTION NO. 2002-85, RECORDED NOVEMBER 19, 2002 AS RECEPTION NO. 20211173.
A.P.N.: 5699-104-07-008
Also known by street and number as: 33 D Place, Pagosa Springs, CO 81147
NOTICE OF SALE
The current holder of the Evidence of Debt secured by the Deed of Trust, described herein, has filed Notice of Election and Demand for sale as provided by law and in said Deed of Trust.
THEREFORE, Notice Is Hereby Given that I will at public auction, at 10:00 A.M. on Thursday, 05/26/2011, at 449 San Juan St., Pagosa Springs, CO 81147, sell to the highest and best bidder for cash, the said real property and all interest of the said Grantor(s), Grantor(s)’ heirs and assigns therein, for the purpose of paying the indebtedness provided in said Evidence of Debt secured by the Deed of Trust, plus attorneys’ fees, the expenses of sale and other items allowed by law, and will issue to the purchaser a Certificate of Purchase, all as provided by law.
First Publication: 3/31/2011
Last Publication: 4/28/2011
Name of Publication: Pagosa Springs Sun
DATE: 01/26/2011
Betty A. Diller, Public Trustee in and for the County of Archuleta, State of Colorado
By: /s/ Betty A. Diller, Public Trustee
The name, address, telephone number and bar registration number of the attorney(s) representing the legal holder of the indebtedness is:
Cristel D. Shepherd #39351
Deanne R. Stodden #33214
Jennifer C. Rogers #34682
Christopher T. Groen #39976
Jeffrey C. Gaston #40389
Jeffrey C. Gaston #40389
Elizabeth S. Marcus #16092
Britney Beall-Eder #64935
Kimberly L. Martinez #40351
Jason C. Hilliard #40856
Caren Jacobs Castle #11790
Barbara Bader #10394
Katharine E. Fisher #39230
Anthony L. Converse #40212
Castle Stawiarski, LLC 999 18TH ST., #2201, DENVER, CO 80202 (303) 865-1400
The attorney above is acting as a debt collector and is attempting to collect a debt. Any information provided may be used for that purpose.
Attorney file #: 10-19538
©Colorado Public Trustees’ Association Revised 12/2009
Published March 31, April 7, 14, 21 and 28, 2011 in The Pagosa Springs SUN.
_________________________________________
COMBINED NOTICE - PUBLICATION
CRS §38-38-103 FORECLOSURE
SALE NO. 2011-015
To Whom It May Concern: This Notice is given with regard to the following described Deed of Trust:
On January 26, 2011, the undersigned Public Trustee caused the Notice of Election and Demand relating to the Deed of Trust described below to be recorded in the County of Archuleta records.
Original Grantor(s): Jenny Lee Hall Stewart
Original Beneficiary(ies): Abundance Mortgage, Inc.
Current Holder of Evidence of Debt: Central Mortgage Company
Date of Deed of Trust: 5/30/2002
County of Recording: Archuleta
Recording Date of Deed of Trust: 6/3/2002
Recording Reception Number: 20205015
Original Principal Amount: $104,000.00
Outstanding Principal Balance: $95,055.19
Pursuant to CRS §38-38-101(4)(i), you are hereby notified that the covenants of the deed of trust have been violated as follows: failure to pay principal and interest when due together with all other payments provided for in the evidence of debt secured by the deed of trust and other violations thereof.
THE LIEN FORECLOSED MAY NOT BE A FIRST LIEN.
THE PROPERTY DESCRIBED HEREIN IS ALL OF THE PROPERTY CURRENTLY ENCUMBERED BY THE LIEN OF THE DEED OF TRUST.
LOT 17, 18 AND 19IN ASPEN SPRINGS SUBDIVISION NO. 6, ACCORDING TO PLAT THEREOF FILED FOR RECORD AUGUST 3, 1971 AS RESEPTION NO. 74689.
Also known by street and number as: 75 Lemon Court, Pagosa Springs, CO 81147
NOTICE OF SALE
The current holder of the Evidence of Debt secured by the Deed of Trust, described herein, has filed Notice of Election and Demand for sale as provided by law and in said Deed of Trust.
THEREFORE, Notice Is Hereby Given that I will at public auction, at 10:00 A.M. on Thursday, 05/26/2011, at 449 San Juan St., Pagosa Springs, CO 81147, sell to the highest and best bidder for cash, the said real property and all interest of the said Grantor(s), Grantor(s)’ heirs and assigns therein, for the purpose of paying the indebtedness provided in said Evidence of Debt secured by the Deed of Trust, plus attorneys’ fees, the expenses of sale and other items allowed by law, and will issue to the purchaser a Certificate of Purchase, all as provided by law.
First Publication: 3/31/2011
Last Publication: 4/28/2011
Name of Publication: Pagosa Springs Sun
DATE: 01/26/2011
Betty A. Diller, Public Trustee in and for the County of Archuleta, State of Colorado
By: /s/ Betty A. Diller, Public Trustee
The name, address, telephone number and bar registration number of the attorney(s) representing the legal holder of the indebtedness is:
Cristel D. Shepherd #39351
Deanne R. Stodden #33214
Jennifer C. Rogers #34682
Christopher T. Groen #39976
Jeffrey C. Gaston #40389
Jeffrey C. Gaston #40389
Elizabeth S. Marcus #16092
Britney Beall-Eder #64935
Kimberly L. Martinez #40351
Jason C. Hilliard #40856
Caren Jacobs Castle #11790
Barbara Bader #10394
Katharine E. Fisher #39230
Anthony L. Converse #40212
Castle Stawiarski, LLC 999 18TH ST., #2201, DENVER, CO 80202 (303) 865-1400
The attorney above is acting as a debt collector and is attempting to collect a debt. Any information provided may be used for that purpose.
Attorney file #: 11-00848
©Colorado Public Trustees’ Association Revised 12/2009
Published March 31, April 7, 14, 21 and 28, 2011 in The Pagosa Springs SUN.
_________________________________________
COMBINED NOTICE - PUBLICATION
CRS §38-38-103 FORECLOSURE
SALE NO. 2011-016
To Whom It May Concern: This Notice is given with regard to the following described Deed of Trust:
On January 27, 2011, the undersigned Public Trustee caused the Notice of Election and Demand relating to the Deed of Trust described
below to be recorded in the County of Archuleta records.
Original Grantor(s): Andrew Spada III and Billie K Spada
Original Beneficiary(ies): Citizens Bank of Pagosa Springs
Current Holder of Evidence of Debt: Citizens Bank of Pagosa Springs
Date of Deed of Trust: 6/28/2007
County of Recording: Archuleta
Recording Date of Deed of Trust: 7/9/2007
Recording Reception Number: 20706010
Original Principal Amount: $975,000.00
Outstanding Principal Balance: $960,362.25
Pursuant to CRS §38-38-101(4)(i), you are hereby notified that the covenants of the deed of trust have been violated as follows: failure to
pay principal and interest when due together with all other payments provided for in the evidence of debt secured by the deed of trust and
other violations thereof.
THE LIEN FORECLOSED MAY NOT BE A FIRST LIEN.
THE PROPERTY DESCRIBED HEREIN IS ALL OF THE PROPERTY CURRENTLY ENCUMBERED BY THE LIEN OF THE DEED
OF TRUST.
Please see attached Exhibit A.
EXHIBIT A
Order Number: 200715477
LEGAL DESCRIPTION
A parcel of land located in Sections 19 and 30, Township 36 North, Range 2 West, N.M.P.M., Archuleta County, Colorado, more particularly described as follows:
Commencing at the North Quarter corner of said Section 29 and considering the East line of the N 1/2 NE 1/4 NW 1/4 to bear South 00°55’03” East with all bearings contained herein relative thereof;
Thence North 68°35’42” West a distance of 3869.37 feet to the true point of beginning;
Thence South 00°00’00” West a distance of 2709.66 feet;
Thence South 66°09’28” West a distance of 105.05 feet;
Thence North 82°45’26” West a distance of 303.74 feet;
Thence along the arc of a curve to the right whose central angle is 40°05’43” and whose radius is 440.00 feet an arc distance of 307.91 fee;
Thence North 42°39’42” West a distance of 247.13 feet;
Thence South 08°09’32” East a distance of 98.94 feet;
Thence South 88°48’51” West a distance of 29.84 feet;
Thence South 89°00’55” West a distance of 733.29 feet;
Thence North 00°33’34” West a distance of 1112.55 feet;
Thence North 00°25’28” East a distance of 1279.68 feet;
Thence South 67°27’08” East a distance of 484.15 feet;
Thence North 20°37’24” West a distance of 137.97 feet;
Thence along the arc of a curve to the left whose central angle is 18°01’10” and whose radius is 1000.00 feet an arc distance of 314.50 feet;
Thence North 38°38’35” West a distance of 1026.47 feet;
Thence along the arc of a curve to the left whose central angle is 09°46’57” and whose radius is 800.00 feet an arc distance of 136.59 feet;
Thence North 48°25’32” West a distance of 169.37 feet;
Thence North 89°51’20” East a distance of 45.08 feet;
Thence North 89°52’17” East, a distance of 1702.85 feet;
Thence South 00°14’56” East a distance of 1127.55 feet;
Thence North 89°01’17” East a distance of 448.54 feet to the Point of Beginning.
Also known by street and number as: 2675 Preservation Place, Pagosa Springs, CO 81147
NOTICE OF SALE
The current holder of the Evidence of Debt secured by the Deed of Trust, described herein, has filed Notice of Election and Demand for sale
as provided by law and in said Deed of Trust.
THEREFORE, Notice Is Hereby Given that I will at public auction, at 10:00 A.M. on Thursday, 05/26/2011, at 449 San Juan St., Pagosa Springs, CO 81147, sell to the highest and best bidder for cash, the said real property and all interest of the said Grantor(s), Grantor(s)’ heirs and assigns therein, for the purpose of paying the indebtedness provided in said Evidence of Debt secured by the Deed of Trust, plus attorneys’ fees, the expenses of sale and other items allowed by law, and will issue to the purchaser a Certificate of Purchase, all as provided by law.
First Publication: 3/31/2011
Last Publication: 4/28/2011
Name of Publication: Pagosa Springs Sun
DATE: 01/27/2011
Betty A. Diller, Public Trustee in and for the County of Archuleta, State of Colorado
By: /s/ Betty A. Diller, Public Trustee
The name, address, telephone number and bar registration number of the attorney(s) representing the legal holder of the indebtedness is:
William J. Darling ##32929
William J. Darling P O Box 959, Pagosa Springs, CO 81147 (970) 731-4580
The attorney above is acting as a debt collector and is attempting to collect a debt. Any information provided may be used for
that purpose.
Attorney file #: CI70-036
©Colorado Public Trustees’ Association Revised 12/2009
Published March 31, April 7, 14, 21 and 28, 2011 in The Pagosa Springs SUN.
_________________________________________
District Court, Archuleta County, State of Colorado
Court Address: PO Box 148, 449 San Juan St.
Pagosa Springs, CO 81147
EAGLE’S LOFT PROPERTY OWNERS ASSOCIATION, INC.
Plaintiffs,
vs.
LEONARD D. SCOTT, THE ESTATE OF LEONARD D. SCOTT, THE PERSONAL REPRESENTATIVE OF LEONARD D. SCOTT, THE HEIRS AND DEVISEES OF LEONARD D. SCOTT, JUDY A. SCOTT and All Unknown Persons Who Claim Any Interest In The Subject Matter Of This Action,
Defendants.
Attorney for Plaintiffs:
Larry W. Holthus
PO Box 1737
Pagosa Springs, CO 81147
Phone Number: (970) 264-4196
FAX Number: (970) 264-4197
Atty. Reg. #: 10535
Case Number: 10CV316
SUMMONS BY PUBLICATION
THE PEOPLE OF THE STATE OF COLORADO TO THE ABOVE NAMED DEFENDANTS:
You are hereby summoned and required to appear and defend against the claims of the Complaint filed with the Court in this action, by filing with the Clerk of this Court, an Answer or other response. You are required to file your Answer or other response within thirty (30) days after the date of the last publication. A copy of the Complaint may be obtained from the Clerk of the Court.
If you fail to file your Answer or other response to the Complaint in writing within thirty (30) days after the date of the last publication, judgment by default may be rendered against you by the Court for the relief demanded in the Complaint without further notice.
This is an action to quiet title to:
Unit Number 38, Building Number 38, Unit Week Number 15 , in “EAGLE’S LOFT – Phase Three, as Reception No. 130203 and in accordance with and as limited and defined by the Declaration of Individual and/or Interval Ownership, recorded under Reception Number 117700 in Book 200 at Page 834 et seq and amendments and supplements thereto in the Office of the County Clerk and Recorder in and for Archuleta County, Colorado.
Dated this 10th day of March, 2011.
/s/ Larry W. Holthus
Larry W. Holthus
Published March 31, April 7, 14, 21 and 28, 2011 in The Pagosa Springs SUN.
_________________________________________
District Court, Archuleta County, State of Colorado
Court Address: PO Box 148, 449 San Juan St.
Pagosa Springs, CO 81147
PTARMIGAN PROPERTY OWNERS ASSOCIATION, INC.
Plaintiffs,
vs.
ALFRED E. FRIZZELL, MARIANNE FRIZZELL, THE ESTATE OF ALFRED E. FRIZZELL, THE PERSONAL REPRESENTATIVE OF ALFRED E. FRIZZELL, THE HEIRS AND DEVISEES OF ALFRED E. FRIZZELL, THE ESTATE OF MARIANNE FRIZZELL, THE PERSONAL REPRESENTATIVE OF MARIANNE FRIZZELL, THE HEIRS AND DEVISEES OF MARIANNE FRIZZELL and All Unknown Persons Who Claim Any Interest In The Subject Matter Of This Action,
Defendant.
Attorney for Plaintiffs:
Larry W. Holthus
PO Box 1737
Pagosa Springs, CO 81147
Phone Number: (970) 264-4196
Atty. Reg. #: 10535
FAX Number: (970) 264-4197
Email: ronin47@centurytel.net
Case Number: 11 CV 73
SUMMONS BY PUBLICATION
THE PEOPLE OF THE STATE OF COLORADO TO THE ABOVE NAMED DEFENDANTS:
You are hereby summoned and required to appear and defend against the claims of the Complaint filed with the Court in this action, by filing with the Clerk of this Court, an Answer or other response. You are required to file your Answer or other response within thirty (30) days after the date of the last publication. A copy of the Complaint may be obtained from the Clerk of the Court.
If you fail to file your Answer or other response to the Complaint in writing within thirty (30) days after the date of the last publication, judgment by default may be rendered against you by the Court for the relief demanded in the Complaint without further notice.
This is an action to quiet title to:
Unit Week Number 41, Unit Number 7217, Building Number 09, in “Ptarmigan Townhouses Phase III, as recorded under Reception No. 156202, subject to Declaration of Individual and/or Interval Ownership for Ptarmigan Townhouses recorded under Reception Number 153557 and amendments and supplements thereto in the Office of the County Clerk and Recorder in and for Archuleta County, Colorado.
Dated this 11th day of March, 2011.
/s/ Larry W. Holthus
Larry W. Holthus
Published March 31, April 7, 14, 21 and 28, 2011 in The Pagosa Springs SUN.
_________________________________________
District Court, Archuleta County, State of Colorado
Court Address: PO Box 148, 449 San Juan St.
Pagosa Springs, CO 81147
PTARMIGAN PROPERTY OWNERS ASSOCIATION, INC.
Plaintiffs,
vs.
HARRIET M. GUTHRIE, THE ESTATE OF HARRIET M. GUTHRIE, THE PERSONAL REPRESENTATIVE OF HARRIET M. GUTHRIE, THE HEIRS AND DEVISEES OF HARRIET M. GUTHRIE, and All Unknown Persons Who Claim Any Interest in the Subject Matter of This Action,
Defendants.
Attorney for Plaintiffs:
Larry W. Holthus
PO Box 1737
Pagosa Springs, CO 81147
Phone Number: (970) 264-4196
FAX Number: (970) 264-4197
Atty. Reg. #: 10535
Case Number: 11 CV70
SUMMONS BY PUBLICATION
THE PEOPLE OF THE STATE OF COLORADO TO THE ABOVE NAMED DEFENDANTS:
You are hereby summoned and required to appear and defend against the claims of the Complaint filed with the Court in this action, by filing with the Clerk of this Court, an Answer or other response. You are required to file your Answer or other response within thirty (30) days after the date of the last publication. A copy of the Complaint may be obtained from the Clerk of the Court.
If you fail to file your Answer or other response to the Complaint in writing within thirty (30) days after the date of the last publication, judgment by default may be rendered against you by the Court for the relief demanded in the Complaint without further notice.
This is an action to quiet title to:
Unit Week Number 35, Unit Number 7201, Building Number 01, in “Ptarmigan Townhouses Phase I, as recorded under Reception No. 153256 subject to Declaration of Individual and/or Interval Ownership for Ptarmigan Townhouses recorded under Reception Number 153557 and amendments and supplements thereto in the Office of the County Clerk and Recorder in and for Archuleta County, Colorado.
Dated this 10th day of March, 2009.
/s/ Larry W. Holthus
Larry W. Holthus
Published March 31, April 7, 14, 21 and 28, 2011 in The Pagosa Springs SUN.
_________________________________________
District Court, Archuleta County, State of Colorado
Court Address: PO Box 148, 449 San Juan St.
Pagosa Springs, CO 81147
PTARMIGAN PROPERTY OWNERS ASSOCIATION, INC.
Plaintiffs,
vs.
FRANCIS A. GUTHRIE AND HARRIET M. GUTHRIE, Husband & Wife, THE ESTATE OF FRANCIS A. GUTHRIE, THE PERSONAL REPRESENTATIVE OF FRANCIS A. GUTHRIE, THE HEIRS AND DEVISEES OF FRANCIS A. GUTHRIE, THE ESTATE OF HARRIET M. GUTHRIE, THE PERSONAL REPRESENTATIVE OF HARRIET M. GUTHRIE, THE HEIRS AND DEVISEES OF HARRIET M. GUTHRIE and All Unknown Persons Who Claim Any Interest In The Subject Matter Of This Action,
Defendant.
Attorney for Plaintiffs:
Larry W. Holthus
PO Box 1737
Pagosa Springs, CO 81147
Phone Number: (970) 264-4196 FAX Number: (970) 264-4197
Atty. Reg. #: 10535 Email: ronin47@centurytel.net
Case Number: 11 CV72
SUMMONS BY PUBLICATION
THE PEOPLE OF THE STATE OF COLORADO TO THE ABOVE NAMED DEFENDANTS:
You are hereby summoned and required to appear and defend against the claims of the Complaint filed with the Court in this action, by filing with the Clerk of this Court, an Answer or other response. You are required to file your Answer or other response within thirty (30) days after the date of the last publication. A copy of the Complaint may be obtained from the Clerk of the Court.
If you fail to file your Answer or other response to the Complaint in writing within thirty (30) days after the date of the last publication, judgment by default may be rendered against you by the Court for the relief demanded in the Complaint without further notice.
This is an action to quiet title to:
Unit Week Number 32, Unit Number 7224, Building Number 12, in “Ptarmigan Townhouses Phase IV, as recorded under Reception No. 159241 subject to Declaration of Individual and/or Interval Ownership for Ptarmigan Townhouses recorded under Reception Number 153557 and amendments and supplements thereto in the Office of the County Clerk and Recorder in and for Archuleta County, Colorado.
Dated this 10th day of March, 2011.
/s/ Larry W. Holthus
Larry W. Holthus
Published March 31, April 7, 14, 21 and 28, 2011 in The Pagosa Springs SUN.
_________________________________________
COMBINED NOTICE - PUBLICATION
CRS §38-38-103 FORECLOSURE
SALE NO. 2011-010
To Whom It May Concern: This Notice is given with regard to the following described Deed of Trust:
On January 19, 2011, the undersigned Public Trustee caused the Notice of Election and Demand relating to the Deed of Trust described below to be recorded in the County of Archuleta records.
Original Grantor(s): RICK L. ERVIN AND LYNNETTE M. ERVIN
Original Beneficiary(ies): MORTGAGE ELECTRONIC REGISTRATION SYSTEMS, INC., AS NOMINEE FOR EQUIFIRST CORPORATION
Current Holder of Evidence of Debt: HSBC BANK USA, NATIONAL ASSOCIATION, AS TRUSTEE, FOR THE REGISTERED HOLDERS OF NOMURA HOME EQUITY HOME LOAN, INC. ASSET-BACKED CERTIFICATES, SERIES 2007-2
Date of Deed of Trust: 7/7/2006
County of Recording: Archuleta
Recording Date of Deed of Trust: 7/25/2006
Recording Reception Number: 20607080
Original Principal Amount: $269,555.00
Outstanding Principal Balance: $273,619.61
Pursuant to CRS §38-38-101(4)(i), you are hereby notified that the covenants of the deed of trust have been violated as follows: failure to pay principal and interest when due together with all other payments provided for in the evidence of debt secured by the deed of trust and other violations thereof.
THE LIEN FORECLOSED MAY NOT BE A FIRST LIEN.
THE PROPERTY DESCRIBED HEREIN IS ALL OF THE PROPERTY CURRENTLY ENCUMBERED BY THE LIEN OF THE DEED OF TRUST.
SEE ATTACHED EXHIBIT A
EXHIBIT “A”
Current Owner: Rick L. Ervin and Lynette M. Ervin
All that real property, if any, situate, lying and being in the County of Archuleta and State of Colorado described as follows:
Lot 42 of Block 15 in Lake Pagosa Park, according to the plat thereof filed for record March 13, 1970 as Reception No. 72998.
Being the same premises conveyed to Rick L. Ervin and Lynette M. Ervin from Jeffrey W. Hudson and Kellie L. Hudson by Warranty Deed dated 8/10/2005 and recorded 8/16/2005 as Instrument or Book/Page No. 20508464 of the Archuleta County Clerk’s Office. Who further acquired title from Jose and Sharon Quintana by virtue of a deed recorded 9/3/2002 as Instrument or Book/Page No. 20207960.
SHOWN FOR INFORMATIONAL PURPOSES ONLY:
ADDRESS: 280 Inspiration Dr, Pagosa Springs, CO 81147
PARCEL ID: 569908308003
Also known by street and number as: 280 INSPIRATION DRIVE, PAGOSA SPRINGS, CO 81147
NOTICE OF SALE
The current holder of the Evidence of Debt secured by the Deed of Trust, described herein, has filed Notice of Election and Demand for sale as provided by law and in said Deed of Trust.
THEREFORE, Notice Is Hereby Given that I will at public auction, at 10:00 A.M. on Thursday, 05/19/2011, at 449 San Juan St., Pagosa Springs, CO 81147, sell to the highest and best bidder for cash, the said real property and all interest of the said Grantor(s), Grantor(s)’ heirs and assigns therein, for the purpose of paying the indebtedness provided in said Evidence of Debt secured by the Deed of Trust, plus attorneys’ fees, the expenses of sale and other items allowed by law, and will issue to the purchaser a Certificate of Purchase, all as provided by law.
First Publication: 3/24/2011
Last Publication: 4/21/2011
Name of Publication: Pagosa Springs Sun
DATE: 01/19/2011
Betty A. Diller, Public Trustee in and for the County of Archuleta, State of Colorado
By: /s/ Betty A. Diller, Public Trustee
The name, address, telephone number and bar registration number of the attorney(s) representing the legal holder of the indebtedness is:
Vaden Law Firm LLC Attorneys at Law, P O Box 18997, Denver, CO 80218 (877) 245-1529
The attorney above is acting as a debt collector and is attempting to collect a debt. Any information provided may be used for that purpose.
Attorney file #: 10-051-01318
©Colorado Public Trustees’ Association Revised 12/2009
Published March 24, 31, April 7, 14 and 21, 2011 in The Pagosa Springs SUN.
_________________________________________
COMBINED NOTICE - PUBLICATION
CRS §38-38-103 FORECLOSURE
SALE NO. 2011-012
To Whom It May Concern: This Notice is given with regard to the following described Deed of Trust:
On January 19, 2011, the undersigned Public Trustee caused the Notice of Election and Demand relating to the Deed of Trust described below to be recorded in the County of Archuleta records.
Original Grantor(s): Robert S. Gisburne and Rebecca L. Gisburne
Original Beneficiary(ies): Wells Fargo Home Mortgage, Inc.
Current Holder of Evidence of Debt: US Bank National Association, as Trustee for WFASC 2003-9
Date of Deed of Trust: 6/13/2003
County of Recording: Archuleta
Recording Date of Deed of Trust: 6/23/2003
Recording Reception Number: 20306128
Original Principal Amount: $799,000.00
Outstanding Principal Balance: $565,399.74
Pursuant to CRS §38-38-101(4)(i), you are hereby notified that the covenants of the deed of trust have been violated as follows: failure to pay principal and interest when due together with all other payments provided for in the evidence of debt secured by the deed of trust and other violations thereof.
THE LIEN FORECLOSED MAY NOT BE A FIRST LIEN.
THE PROPERTY DESCRIBED HEREIN IS ALL OF THE PROPERTY CURRENTLY ENCUMBERED BY THE LIEN OF THE DEED OF TRUST.
LOT 37, PIEDRA ESTATES, ACCORDING TO THE PLAT THEREOF FILED FOR RECORD DECEMBER 7, 1976 AS RCEPTION NO. 86891.
Also known by street and number as: 1547 Oren Road, Pagosa Springs, CO 81147
NOTICE OF SALE
The current holder of the Evidence of Debt secured by the Deed of Trust, described herein, has filed Notice of Election and Demand for sale as provided by law and in said Deed of Trust.
THEREFORE, Notice Is Hereby Given that I will at public auction, at 10:00 A.M. on Thursday, 05/19/2011, at 449 San Juan St., Pagosa Springs, CO 81147, sell to the highest and best bidder for cash, the said real property and all interest of the said Grantor(s), Grantor(s)’ heirs and assigns therein, for the purpose of paying the indebtedness provided in said Evidence of Debt secured by the Deed of Trust, plus attorneys’ fees, the expenses of sale and other items allowed by law, and will issue to the purchaser a Certificate of Purchase, all as provided by law.
First Publication: 3/24/2011
Last Publication: 4/21/2011
Name of Publication: Pagosa Springs Sun
DATE: 01/19/2011
Betty A. Diller, Public Trustee in and for the County of Archuleta, State of Colorado
By: /s/ Betty A. Diller, Public Trustee
The name, address, telephone number and bar registration number of the attorney(s) representing the legal holder of the indebtedness is:
Cristel D. Shepherd #39351
Deanne R. Stodden #33214
Jennifer C. Rogers #34682
Christopher T. Groen #39976
Jeffrey C. Gaston #40389
Jeffrey C. Gaston #40389
Elizabeth S. Marcus #16092
Britney Beall-Eder #64935
Kimberly L. Martinez #40351
Jason C. Hilliard #40856
Caren Jacobs Castle #11790
Barbara Bader #10394
Katharine E. Fisher #39230
Anthony L. Converse #40212
Castle Stawiarski, LLC 999 18TH ST., #2201, DENVER, CO 80202 (303) 865-1400
The attorney above is acting as a debt collector and is attempting to collect a debt. Any information provided may be used for that purpose.
Attorney file #: 09-17926R
©Colorado Public Trustees’ Association Revised 12/2009
Published March 24, 31, April 7, 14 and 21, 2011 in The Pagosa Springs SUN.
_________________________________________
COMBINED NOTICE - PUBLICATION
CRS §38-38-103 FORECLOSURE
SALE NO. 2011-011
To Whom It May Concern: This Notice is given with regard to the following described Deed of Trust:
On January 19, 2011, the undersigned Public Trustee caused the Notice of Election and Demand relating to the Deed of Trust described below to be recorded in the County of Archuleta records.
Original Grantor(s): Dorothy Trefethen
Original Beneficiary(ies): Washington Mutual Bank, FA
Current Holder of Evidence of Debt: JPMorgan Chase Bank, National Association
Date of Deed of Trust: 10/30/2007
County of Recording: Archuleta
Recording Date of Deed of Trust: 11/5/2007
Recording Reception Number: 20710304
Original Principal Amount: $200,000.00
Outstanding Principal Balance: $193,779.41
Pursuant to CRS §38-38-101(4)(i), you are hereby notified that the covenants of the deed of trust have been violated as follows: failure to pay principal and interest when due together with all other payments provided for in the evidence of debt secured by the deed of trust and other violations thereof.
THE LIEN FORECLOSED MAY NOT BE A FIRST LIEN.
THE PROPERTY DESCRIBED HEREIN IS ALL OF THE PROPERTY CURRENTLY ENCUMBERED BY THE LIEN OF THE DEED OF TRUST.
LOT 33A, PAGOSA HILLS SUBDIVISION NO. 4, RE-PLAT OF LOTS 1-4, 8-10, 17, 19 AND 32-36, ACCORDING TO THE PLAT THEREOF FILED JUNE 21, 1977, AS RECPETION NO. 88397, IN THE OFFICE OF THE CLERK AND RECORDER, ARCHULETA COUNTY, COLORADO.
Also known by street and number as: 508 Rainbow Drive, Pagosa Springs, CO 81147
NOTICE OF SALE
The current holder of the Evidence of Debt secured by the Deed of Trust, described herein, has filed Notice of Election and Demand for sale as provided by law and in said Deed of Trust.
THEREFORE, Notice Is Hereby Given that I will at public auction, at 10:00 A.M. on Thursday, 05/19/2011, at 449 San Juan St., Pagosa Springs, CO 81147, sell to the highest and best bidder for cash, the said real property and all interest of the said Grantor(s), Grantor(s)’ heirs and assigns therein, for the purpose of paying the indebtedness provided in said Evidence of Debt secured by the Deed of Trust, plus attorneys’ fees, the expenses of sale and other items allowed by law, and will issue to the purchaser a Certificate of Purchase, all as provided by law.
First Publication: 3/24/2011
Last Publication: 4/21/2011
Name of Publication: Pagosa Springs Sun
DATE: 01/19/2011
Betty A. Diller, Public Trustee in and for the County of Archuleta, State of Colorado
By: /s/ Betty A. Diller, Public Trustee
The name, address, telephone number and bar registration number of the attorney(s) representing the legal holder of the indebtedness is:
Robert J. Hopp #26818
Wayne E. Vaden #21026
Robert J Hopp and Associates LLC P.O. Box 8689, Denver, CO 80201 (303) 225-0800
The attorney above is acting as a debt collector and is attempting to collect a debt. Any information provided may be used for that purpose.
Attorney file #: 11-00388CO
©Colorado Public Trustees’ Association Revised 12/2009
Published March 24, 31, April 7, 14 and 21, 2011 in The Pagosa Springs SUN.
_________________________________________
District Court, Archuleta County, State of Colorado
Court Address: 449 San Juan Street, P.O. Box 148
Pagosa Springs, Colorado 81147
Telephone No.: (970) 264-2400
EAGLE’S LOFT PROPERTY OWNERS ASSOCIATION, INC.
Plaintiff
v.
CHARLES E. SCATES, THE ESTATE OF CHARLES E. SCATES, THE PERSONAL REPRESENTATIVE OF CHARLES E. SCATES, THE HEIRS AND DEVISEES OF CHARLES E. SCATES, IVA G. SCATES, THE ESTATE OF IVA G.. SCATES, THE PERSONAL REPRESENTATIVE OF IVA G. SCATES, HEIRS AND DEVISEES OF IVA G. SCATES and All Unknown Persons Who Claim Any Interest In The Subject Matter Of This Action,
Defendant.
Attorney for Plaintiff:
Name: Larry W. Holthus
Address: P.O. Box 1737
Pagosa Springs, Colorado 81147
Telephone No.: (970) 264-4196
Facsimile No.: (970) 264-4197
Atty. Reg. No.: 10535
Case Number: 10CV263
SHERIFF’S COMBINED NOTICE OF SALE, RIGHT TO CURE AND RIGHT TO REDEEM
TO WHOM IT MAY CONCERN:
This is to advise you that the above-captioned action is pending. A Judgment and Decree for Judicial Foreclosure has been entered in this action concerning an assessment lien by the plaintiff Eagle’s Loft Property Owners Association, Inc. pursuant to the Colorado Common Interest Ownership Act, Colorado Revised Statutes, §3-33.3-316(2)(a), and the Plaintiff’s Property Owners Association Declaration for Eagle’s Loft Property Owners Association, Inc. of (said) Assessment Lien being recorded on August 23, 2010 at Reception No. 21005678, in the office of the Clerk and Recorders Office of Archuleta County, Colorado (the “Assessment Lien”).
The real property which is the subject matter of this litigation, which is the property subject to the Assessment Lien, is situation in Archuleta County, and is described as follows, to-wit:
Unit Number 42 Building Number 42, Unit Week Number 18, in “EAGLE’S LOFT – Phase IV, as Reception No. 137941 and in accordance with and as limited and defined by the Declaration of Individual and/or Interval Ownership, recorded under Reception Number 117700 in Book 200 at Page 834 et seq and amendments and supplements thereto in the Office of the County Clerk and Recorder in and for Archuleta County, Colorado.
The Plaintiff named above is the judgment creditor in this action and the lienor of the property pursuant to the Colorado Common Interest Ownership Act, Colorado revised Statutes, §33-33.3-316(2)(a), and the Plaintiff’s Property Owners Association Declaration for Eagles’ Loft Property Owners Association. As of March 1, 2011, the outstanding balance due and owing on such judgment is $2,660.94.
I shall offer for public sale to the highest bidder, for case, at public auction, all the right, title and interest of the defendants in said property on July 06, 2011 at 10:00 a.m. at the Archuleta County Sheriff’s Office, 449 San Juan St., Pagosa Springs, CO 81147.
NOTE: THE LIEN BEING FORECLOSED MAY NOT BE A FIRST LIEN.
Attached hereto are copies of certain Colorado statutes that my vitally affect your property rights in relation to this proceeding. Said proceeding may result in the loss of property in which you have an interest. You may wish to seek the advice of your own private attorney concerning your rights in relation to this foreclosure proceeding.
C.R.S. §38-38-103(4)(a)(II): A notice of intent to cure filed pursuant to section 38-38-104 shall be filed with the officer at least fifteen calendar days prior to the first scheduled sale date or any date to which the sale is continued;
C.R.S. §38-38-103(4)(a)(III): A notice of intent to redeem filed pursuant to section 38-38-302 shall be filed with the officer no later than eight business days after the sale;
INTENT to cure and redeem, as provided by the aforementioned laws, must be directed to or conducted at the Office of the Sheriff for the County of Archuleta, Front Office, 449 San Juan Street, Pagosa Springs, CO 81147.
Dated at Archuleta County, Colorado, this 18th day of March, 2011.
/s/ Peter L. Gonzalez
Peter L. Gonzalez
Sheriff, Archuleta County, Colorado
Sale Date: July 06, 2011. at 10:00 a.m..
BIDDERS ARE REQUIRED TO HAVE CASH OR CERTIFIED FUNDS TO COVER THEIR HIGHEST BID AT THE TIME OF THE SALE. CERTIFIED FUNDS ARE PAYABLE TO THE REGISTRY OF THE ARCHULETA COUNTY DISTRICT COURT.
Colorado Statutes attached: Colorado Revised Statutes §38-37-108, 38-38-103, 38-38-104,38-38-301,38-38-304,38-38-305, and 38-38-306.
Published March 24, 31, April 7, 14 and 21, 2011 in The Pagosa Springs SUN.
_________________________________________
District Court, Archuleta County, State of Colorado
Court Address: 449 San Juan Street, P.O. Box 148
Pagosa Springs, Colorado 81147
Telephone No.: (970) 264-2400
EAGLE’S LOFT PROPERTY OWNERS ASSOCIATION, INC.
Plaintiff
v.
GEORGE ZOU, a single man and All Unknown Persons Who Claim Any Interest In The Subject Matter Of This Action,
Defendant.
Attorney for Plaintiff:
Name: Larry W. Holthus
Address: P.O. Box 1737
Pagosa Springs, Colorado 81147
Telephone No.: (970) 264-4196
Facsimile No.: (970) 264-4197
Atty. Reg. No.: 10535
Case Number: 10CV272
SHERIFF’S COMBINED NOTICE OF SALE, RIGHT TO CURE AND RIGHT TO REDEEM
TO WHOM IT MAY CONCERN:
This is to advise you that the above-captioned action is pending. A Judgment and Decree for Judicial Foreclosure has been entered in this action concerning an assessment lien by the plaintiff Eagle’s Loft Property Owners Association, Inc. pursuant to the Colorado Common Interest Ownership Act, Colorado Revised Statutes, §3-33.3-316(2)(a), and the Plaintiff’s Property Owners Association Declaration for Eagle’s Loft Property Owners Association, Inc. of (said) Assessment Lien being recorded on August 23, 2010 at Reception No. 21005685 in the office of the Clerk and Recorders Office of Archuleta County, Colorado (the “Assessment Lien”).
The real property which is the subject matter of this litigation, which is the property subject to the Assessment Lien, is situation in Archuleta County, and is described as follows, to-wit:
Unit Number 06 Building Number 06, Unit Week Number 14, in “EAGLE’S LOFT – Phase One, as Reception No. 122508 and in accordance with and as limited and defined by the Declaration of Individual and/or Interval Ownership, recorded under Reception Number 117700 in Book 200 at Page 834 et seq and amendments and supplements thereto in the Office of the County Clerk and Recorder in and for Archuleta County, Colorado.
The Plaintiff named above is the judgment creditor in this action and the lienor of the property pursuant to the Colorado Common Interest Ownership Act, Colorado revised Statutes, §33-33.3-316(2)(a), and the Plaintiff’s Property Owners Association Declaration for Eagles’ Loft Property Owners Association. As of March 1, 2011, the outstanding balance due and owing on such judgment is $2,673.66.
I shall offer for public sale to the highest bidder, for case, at public auction, all the right, title and interest of the defendants in said property on July 06, 2008 at 10:00 a.m. at the Archuleta County Sheriff’s Office, 449 San Juan St., Pagosa Springs, CO 81147.
NOTE: THE LIEN BEING FORECLOSED MAY NOT BE A FIRST LIEN.
Attached hereto are copies of certain Colorado statutes that my vitally affect your property rights in relation to this proceeding. Said proceeding may result in the loss of property in which you have an interest. You may wish to seek the advice of your own private attorney concerning your rights in relation to this foreclosure proceeding.
C.R.S. §38-38-103(4)(a)(II): A notice of intent to cure filed pursuant to section 38-38-104 shall be filed with the officer at least fifteen calendar days prior to the first scheduled sale date or any date to which the sale is continued;
C.R.S. §38-38-103(4)(a)(III): A notice of intent to redeem filed pursuant to section 38-38-302 shall be filed with the officer no later than eight business days after the sale;
INTENT to cure and redeem, as provided by the aforementioned laws, must be directed to or conducted at the Office of the Sheriff for the County of Archuleta, Front Office, 449 San Juan Street, Pagosa Springs, CO 81147.
Dated at Archuleta County, Colorado, this 18th day of March, 2011
/s/ Peter L. Gonzalez
Peter L. Gonzalez
Sheriff, Archuleta County, Colorado
Sale Date: July 06, 2011 at 10:00 a.m.
BIDDERS ARE REQUIRED TO HAVE CASH OR CERTIFIED FUNDS TO COVER THEIR HIGHEST BID AT THE TIME OF THE SALE. CERTIFIED FUNDS ARE PAYABLE TO THE REGISTRY OF THE ARCHULETA COUNTY DISTRICT COURT.
Colorado Statutes attached: Colorado Revised Statutes §38-37-108, 38-38-103, 38-38-104,38-38-301,38-38-304,38-38-305, and 38-38-306.
Published March 24, 31, April 7, 14 and 21, 2011 in The Pagosa Springs SUN.
_________________________________________
District Court, Archuleta County, State of Colorado
Court Address: 449 San Juan Street, P.O. Box 148
Pagosa Springs, Colorado 81147
Telephone No.: (970) 264-2400
MOUNTAIN MEADOWS PROPERTY OWNERS ASSOCIATION, INC.
Plaintiff
v.
MICK L. BLACKLEDGE, MEITA S. BLACKLEDGE and All Unknown Persons Who Claim Any Interest In The Subject Matter Of This Action,
Defendant.
Attorney for Plaintiff:
Name: Larry W. Holthus
Address: P.O. Box 1737
Pagosa Springs, Colorado 81147
Telephone No.: (970) 264-4196
Facsimile No.: (970) 264-4197
Atty. Reg. No.: 10535
Case Number: 10CV235
SHERIFF’S COMBINED NOTICE OF SALE, RIGHT TO CURE AND RIGHT TO REDEEM
TO WHOM IT MAY CONCERN:
This is to advise you that the above-captioned action is pending. A Judgment and Decree for Judicial Foreclosure has been entered in this action concerning an assessment lien by the plaintiff Mountain Meadows Property Owners Association, Inc. pursuant to the Colorado Common Interest Ownership Act, Colorado Revised Statutes, §3-33.3-316(2)(a), and the Plaintiff’s Property Owners Association Declaration for Mountain Meadows Property Owners Association, Inc. of (said) Assessment Lien being recorded on July 27, 2010 at Reception No. 21004953, in the office of the Clerk and Recorders Office of Archuleta County, Colorado (the “Assessment Lien”).
The real property which is the subject matter of this litigation, which is the property subject to the Assessment Lien, is situation in Archuleta County, and is described as follows, to-wit:
One Winter Unit Week as said Week is numbered and defined in the Declaration of Interval Ownership for Mountain Meadows recorded under Reception No. 137132, and amendments and supplements thereto, and as identified in Unit Numbers 7601 through 7608 of “Mountain Meadows Townhomes – Phase Two” filed for record under Reception No 20209311. Together with a right of ingress and egress over the existing road to Lakeside Drive.
The Plaintiff named above is the judgment creditor in this action and the lienor of the property pursuant to the Colorado Common Interest Ownership Act, Colorado revised Statutes, §33-33.3-316(2)(a), and the Plaintiff’s Property Owners Association Declaration for Mountain Meadows Property Owners Association. As of March 1, 2011, the outstanding balance due and owing on such judgment is $2,795.18.
I shall offer for public sale to the highest bidder, for case, at public auction, all the right, title and interest of the defendants in said property on June 29, 2011 at 10:00 a.m. at the Archuleta County Sheriff’s Office, 449 San Juan St., Pagosa Springs, CO 81147.
NOTE: THE LIEN BEING FORECLOSED MAY NOT BE A FIRST LIEN.
Attached hereto are copies of certain Colorado statutes that my vitally affect your property rights in relation to this proceeding. Said proceeding may result in the loss of property in which you have an interest. You may wish to seek the advice of your own private attorney concerning your rights in relation to this foreclosure proceeding.
C.R.S. §38-38-103(4)(a)(II): A notice of intent to cure filed pursuant to section 38-38-104 shall be filed with the officer at least fifteen calendar days prior to the first scheduled sale date or any date to which the sale is continued;
C.R.S. §38-38-103(4)(a)(III): A notice of intent to redeem filed pursuant to section 38-38-302 shall be filed with the officer no later than eight business days after the sale;
INTENT to cure and redeem, as provided by the aforementioned laws, must be directed to or conducted at the Office of the Sheriff for the County of Archuleta, Front Office, 449 San Juan Street, Pagosa Springs, CO 81147.
Dated at Archuleta County, Colorado, this 18th day of March, 2011.
/s/ Peter L. Gonzalez
Peter L. Gonzalez
Sheriff, Archuleta County, Colorado
Sale Date: June 29, 2011 at 10:00 a.m.
BIDDERS ARE REQUIRED TO HAVE CASH OR CERTIFIED FUNDS TO COVER THEIR HIGHEST BID AT THE TIME OF THE SALE. CERTIFIED FUNDS ARE PAYABLE TO THE REGISTRY OF THE ARCHULETA COUNTY DISTRICT COURT.
Colorado Statutes attached: Colorado Revised Statutes §38-37-108, 38-38-103, 38-38-104,38-38-301,38-38-304,38-38-305, and 38-38-306.
Published March 24, 31, April 7, 14 and 21, 2011 in The Pagosa Springs SUN.
_________________________________________
District Court, Archuleta County, State of Colorado
Court Address: 449 San Juan Street, P.O. Box 148
Pagosa Springs, Colorado 81147
Telephone No.: (970) 264-2400
MOUNTAIN MEADOWS PROPERTY OWNERS ASSOCIATION, INC.
Plaintiff
v.
JUANITA GRIFFITH and All Unknown Persons Who Claim Any Interest In The Subject Matter Of This Action,
Defendant.
Attorney for Plaintiff:
Name: Larry W. Holthus
Address: P.O. Box 1737
Pagosa Springs, Colorado 81147
Telephone No.: (970) 264-4196
Facsimile No.: (970) 264-4197
Atty. Reg. No.: 10535
Case Number: 10CV231
SHERIFF’S COMBINED NOTICE OF SALE, RIGHT TO CURE AND RIGHT TO REDEEM
TO WHOM IT MAY CONCERN:
This is to advise you that the above-captioned action is pending. A Judgment and Decree for Judicial Foreclosure has been entered in this action concerning an assessment lien by the plaintiff Mountain Meadows Property Owners Association, Inc. pursuant to the Colorado Common Interest Ownership Act, Colorado Revised Statutes, §3-33.3-316(2)(a), and the Plaintiff’s Property Owners Association Declaration for Mountain Meadows Property Owners Association, Inc. of (said) Assessment Lien being recorded on July 27, 2010 at Reception No. 21004958, in the office of the Clerk and Recorders Office of Archuleta County, Colorado (the “Assessment Lien”).
The real property which is the subject matter of this litigation, which is the property subject to the Assessment Lien, is situation in Archuleta County, and is described as follows, to-wit:
One (1) Red Unit Week as said Week is defined in the Declaration of Interval Ownership for Mountain Meadows recorded under Reception No. 137132, and amendments and supplements thereto, as identified in Building Number One of “Mountain Meadows Townhomes- Phase One” filed for record under Reception No 137131. Together with a right of ingress and egress over the existing road to Lakeside Drive
The Plaintiff named above is the judgment creditor in this action and the lienor of the property pursuant to the Colorado Common Interest Ownership Act, Colorado revised Statutes, §33-33.3-316(2)(a), and the Plaintiff’s Property Owners Association Declaration for Mountain Meadows Property Owners Association. As of March 1, 2011, the outstanding balance due and owing on such judgment is $2,656.72
I shall offer for public sale to the highest bidder, for case, at public auction, all the right, title and interest of the defendants in said property on June 22, 2011 at 10:00 a.m. at the Archuleta County Sheriff’s Office, 449 San Juan St., Pagosa Springs, CO 81147.
NOTE: THE LIEN BEING FORECLOSED MAY NOT BE A FIRST LIEN.
Attached hereto are copies of certain Colorado statutes that my vitally affect your property rights in relation to this proceeding. Said proceeding may result in the loss of property in which you have an interest. You may wish to seek the advice of your own private attorney concerning your rights in relation to this foreclosure proceeding.
C.R.S. §38-38-103(4)(a)(II): A notice of intent to cure filed pursuant to section 38-38-104 shall be filed with the officer at least fifteen calendar days prior to the first scheduled sale date or any date to which the sale is continued;
C.R.S. §38-38-103(4)(a)(III): A notice of intent to redeem filed pursuant to section 38-38-302 shall be filed with the officer no later than eight business days after the sale;
INTENT to cure and redeem, as provided by the aforementioned laws, must be directed to or conducted at the Office of the Sheriff for the County of Archuleta, Front Office, 449 San Juan Street, Pagosa Springs, CO 81147.
Dated at Archuleta County, Colorado, this 18th day of March, 2011.
/s/ Peter L. Gonzalez
Peter L. Gonzalez
Sheriff, Archuleta County, Colorado
Sale Date: June 22, 2011 at 10:00 a.m.
BIDDERS ARE REQUIRED TO HAVE CASH OR CERTIFIED FUNDS TO COVER THEIR HIGHEST BID AT THE TIME OF THE SALE. CERTIFIED FUNDS ARE PAYABLE TO THE REGISTRY OF THE ARCHULETA COUNTY DISTRICT COURT.
Colorado Statutes attached: Colorado Revised Statutes §38-37-108, 38-38-103, 38-38-104,38-38-301,38-38-304,38-38-305, and 38-38-306.
Published March 24, 31, April 7, 14 and 21, 2011 in The Pagosa Springs SUN.
_________________________________________
District Court, Archuleta County, State of Colorado
Court Address: 449 San Juan Street, P.O. Box 148
Pagosa Springs, Colorado 81147
Telephone No.: (970) 264-2400
MOUNTAIN MEADOWS PROPERTY OWNERS ASSOCIATION, INC.
Plaintiff
v.
KEVIN M. LESLIE, ANNA M. LESLIE and All Unknown Persons Who Claim Any Interest In The Subject Matter Of This Action,
Defendant.
Attorney for Plaintiff:
Name: Larry W. Holthus
Address: P.O. Box 1737
Pagosa Springs, Colorado 81147
Telephone No.: (970) 264-4196
Facsimile No.: (970) 264-4197
Atty. Reg. No.: 10535
Case Number: 10CV232
SHERIFF’S COMBINED NOTICE OF SALE, RIGHT TO CURE AND RIGHT TO REDEEM
TO WHOM IT MAY CONCERN:
This is to advise you that the above-captioned action is pending. A Judgment and Decree for Judicial Foreclosure has been entered in this action concerning an assessment lien by the plaintiff Mountain Meadows Property Owners Association, Inc. pursuant to the Colorado Common Interest Ownership Act, Colorado Revised Statutes, §3-33.3-316(2)(a), and the Plaintiff’s Property Owners Association Declaration for Mountain Meadows Property Owners Association, Inc. of (said) Assessment Lien being recorded on July 27, 2010 at Reception No. 21004960, in the office of the Clerk and Recorders Office of Archuleta County, Colorado (the “Assessment Lien”).
The real property which is the subject matter of this litigation, which is the property subject to the Assessment Lien, is situation in Archuleta County, and is described as follows, to-wit:
One Winter Unit Week as said Week is numbered and defined in the Declaration of Interval Ownership for Mountain Meadows recorded under Reception No. 137132, and amendments & supplements thereto, and as identified in Unit Numbers 7601 through 7608 of Mountain Meadows – Phase Two as described and delineated on the Plat captioned “Mountain Meadows – Phase Two” filed for record under Reception No 20209311. Together with a right of ingress and egress over the existing road to Lakeside Drive
The Plaintiff named above is the judgment creditor in this action and the lienor of the property pursuant to the Colorado Common Interest Ownership Act, Colorado revised Statutes, §33-33.3-316(2)(a), and the Plaintiff’s Property Owners Association Declaration for Mountain Meadows Property Owners Association. As of March 1, 2011, the outstanding balance due and owing on such judgment is $2,588.13
I shall offer for public sale to the highest bidder, for case, at public auction, all the right, title and interest of the defendants in said property on June 22, 2011 at 10:00 a.m. at the Archuleta County Sheriff’s Office, 449 San Juan St., Pagosa Springs, CO 81147.
NOTE: THE LIEN BEING FORECLOSED MAY NOT BE A FIRST LIEN.
Attached hereto are copies of certain Colorado statutes that my vitally affect your property rights in relation to this proceeding. Said proceeding may result in the loss of property in which you have an interest. You may wish to seek the advice of your own private attorney concerning your rights in relation to this foreclosure proceeding.
C.R.S. §38-38-103(4)(a)(II): A notice of intent to cure filed pursuant to section 38-38-104 shall be filed with the officer at least fifteen calendar days prior to the first scheduled sale date or any date to which the sale is continued;
C.R.S. §38-38-103(4)(a)(III): A notice of intent to redeem filed pursuant to section 38-38-302 shall be filed with the officer no later than eight business days after the sale;
INTENT to cure and redeem, as provided by the aforementioned laws, must be directed to or conducted at the Office of the Sheriff for the County of Archuleta, Front Office, 449 San Juan Street, Pagosa Springs, CO 81147.
Dated at Archuleta County, Colorado, this 18th day of March, 2011.
/s/ Peter L. Gonzalez
Peter L. Gonzalez
Sheriff, Archuleta County, Colorado
Sale Date: June 22, 2011 at 10:00 a.m.
BIDDERS ARE REQUIRED TO HAVE CASH OR CERTIFIED FUNDS TO COVER THEIR HIGHEST BID AT THE TIME OF THE SALE. CERTIFIED FUNDS ARE PAYABLE TO THE REGISTRY OF THE ARCHULETA COUNTY DISTRICT COURT.
Colorado Statutes attached: Colorado Revised Statutes §38-37-108, 38-38-103, 38-38-104,38-38-301,38-38-304,38-38-305, and 38-38-306.
Published March 24, 31, April 7, 14 and 21, 2011 in The Pagosa Springs SUN.
_________________________________________
District Court, Archuleta County, State of Colorado
Court Address: 449 San Juan Street, P.O. Box 148
Pagosa Springs, Colorado 81147
Telephone No.: (970) 264-2400
MOUNTAIN MEADOWS PROPERTY OWNERS ASSOCIATION, INC.
Plaintiff
v.
SUSAN NOLAN, THE ESTATE OF SUSAN NOLAN, THE PERSONAL REPRESENTATIVE OF SUSAN NOLAN, THE HEIRS AND DEVISEES OF SUSAN NOLAN and All Unknown Persons Who Claim Any Interest In The Subject Matter Of This Action,
Defendant.
Attorney for Plaintiff:
Name: Larry W. Holthus
Address: P.O. Box 1737
Pagosa Springs, Colorado 81147
Telephone No.: (970) 264-4196
Facsimile No.: (970) 264-4197
Atty. Reg. No.: 10535
Case Number: 10CV271
SHERIFF’S COMBINED NOTICE OF SALE, RIGHT TO CURE AND RIGHT TO REDEEM
TO WHOM IT MAY CONCERN:
This is to advise you that the above-captioned action is pending. A Judgment and Decree for Judicial Foreclosure has been entered in this action concerning an assessment lien by the plaintiff Mountain Meadows Property Owners Association, Inc. pursuant to the Colorado Common Interest Ownership Act, Colorado Revised Statutes, §3-33.3-316(2)(a), and the Plaintiff’s Property Owners Association Declaration for Mountain Meadows Property Owners Association, Inc. of (said) Assessment Lien being recorded on July 27, 2010 at Reception No. 21004961, in the office of the Clerk and Recorders Office of Archuleta County, Colorado (the “Assessment Lien”).
The real property which is the subject matter of this litigation, which is the property subject to the Assessment Lien, is situation in Archuleta County, and is described as follows, to-wit:
One White Unit Week – in Building Number One in Mountain Meadows Phase One, according to the plat thereof filed January 21, 1986 as Reception No. 137131, in the office of the Clerk and Recorder, Archuleta County Colorado.
The Plaintiff named above is the judgment creditor in this action and the lienor of the property pursuant to the Colorado Common Interest Ownership Act, Colorado revised Statutes, §33-33.3-316(2)(a), and the Plaintiff’s Property Owners Association Declaration for Mountain Meadows Property Owners Association. As of March 1, 2011, the outstanding balance due and owing on such judgment is $2,558.49.
I shall offer for public sale to the highest bidder, for case, at public auction, all the right, title and interest of the defendants in said property on June 29, 2011 at 10:00 a.m. at the Archuleta County Sheriff’s Office, 449 San Juan St., Pagosa Springs, CO 81147.
NOTE: THE LIEN BEING FORECLOSED MAY NOT BE A FIRST LIEN.
Attached hereto are copies of certain Colorado statutes that my vitally affect your property rights in relation to this proceeding. Said proceeding may result in the loss of property in which you have an interest. You may wish to seek the advice of your own private attorney concerning your rights in relation to this foreclosure proceeding.
C.R.S. §38-38-103(4)(a)(II): A notice of intent to cure filed pursuant to section 38-38-104 shall be filed with the officer at least fifteen calendar days prior to the first scheduled sale date or any date to which the sale is continued;
C.R.S. §38-38-103(4)(a)(III): A notice of intent to redeem filed pursuant to section 38-38-302 shall be filed with the officer no later than eight business days after the sale;
INTENT to cure and redeem, as provided by the aforementioned laws, must be directed to or conducted at the Office of the Sheriff for the County of Archuleta, Front Office, 449 San Juan Street, Pagosa Springs, CO 81147.
Dated at Archuleta County, Colorado, this 18th day of March, 2011.
/s/ Peter L. Gonzalez
Peter L. Gonzalez
Sheriff, Archuleta County, Colorado
Sale Date: June 29, 2011 at 10:0 a.m.
BIDDERS ARE REQUIRED TO HAVE CASH OR CERTIFIED FUNDS TO COVER THEIR HIGHEST BID AT THE TIME OF THE SALE. CERTIFIED FUNDS ARE PAYABLE TO THE REGISTRY OF THE ARCHULETA COUNTY DISTRICT COURT.
Colorado Statutes attached: Colorado Revised Statutes §38-37-108, 38-38-103, 38-38-104,38-38-301,38-38-304,38-38-305, and 38-38-306.
Published March 24, 31, April 7, 14 and 21, 2011 in The Pagosa Springs SUN.
_________________________________________
COMBINED NOTICE - PUBLICATION
CRS §38-38-103 FORECLOSURE
SALE NO. 2011-008
To Whom It May Concern: This Notice is given with regard to the following described Deed of Trust:
On January 12, 2011, the undersigned Public Trustee caused the Notice of Election and Demand relating to the Deed of Trust described below to be recorded in the County of Archuleta records.
Original Grantor(s): Lonnie D. Patison and Lynda A. Patison
Original Beneficiary(ies): Mortgage Electronic Registration Systems, Inc., as nominee for American Mortgage Network, Inc., a Delaware Corporation
Current Holder of Evidence of Debt: BAC Home Loans Servicing, L.P.
Date of Deed of Trust: 3/24/2006
County of Recording: Archuleta
Recording Date of Deed of Trust: 3/29/2006
Recording Reception Number: 20602850
Original Principal Amount: $232,000.00
Outstanding Principal Balance: $255,503.41
Pursuant to CRS §38-38-101(4)(i), you are hereby notified that the covenants of the deed of trust have been violated as follows: failure to pay principal and interest when due together with all other payments provided for in the evidence of debt secured by the deed of trust and other violations thereof.
THE LIEN FORECLOSED MAY NOT BE A FIRST LIEN.
THE PROPERTY DESCRIBED HEREIN IS ALL OF THE PROPERTY CURRENTLY ENCUMBERED BY THE LIEN OF THE DEED OF TRUST.
SEE EXHIBIT A ATTACHED HERETO AND INCORPORATED HEREIN BY REFERENCE
EXHIBIT A
Lot 592X, being a consolidation of Lots 592 and 593, Lake Forest Estates, according to the plat thereof, recorded June 4, 1973 as Reception No. 77869, and as further defined and described in Resolution No. 200-61, from the Board of County Commissioners, Archuleta County, Colorado, recorded July 11, 2000 as Reception No. 20006316, all in the Office of the Clerk and Recorder, Archuleta County, Colorado.
Also known by street and number as: 299 Stevens Circle, Pagosa Springs, CO 81147
NOTICE OF SALE
The current holder of the Evidence of Debt secured by the Deed of Trust, described herein, has filed Notice of Election and Demand for sale as provided by law and in said Deed of Trust.
THEREFORE, Notice Is Hereby Given that I will at public auction, at 10:00 A.M. on Thursday, 05/12/2011, at 449 San Juan St., Pagosa Springs, CO 81147, sell to the highest and best bidder for cash, the said real property and all interest of the said Grantor(s), Grantor(s)’ heirs and assigns therein, for the purpose of paying the indebtedness provided in said Evidence of Debt secured by the Deed of Trust, plus attorneys’ fees, the expenses of sale and other items allowed by law, and will issue to the purchaser a Certificate of Purchase, all as provided by law.
First Publication: 3/17/2011
Last Publication: 4/14/2011
Name of Publication: Pagosa Springs Sun
DATE: 01/12/2011
Betty A. Diller, Public Trustee in and for the County of Archuleta, State of Colorado
By: /s/ Betty A. Diller, Public Trustee
The name, address, telephone number and bar registration number of the attorney(s) representing the legal holder of the indebtedness is:
Cristel D. Shepherd #39351
Deanne R. Stodden #33214
Jennifer C. Rogers #34682
Christopher T. Groen #39976
Jeffrey C. Gaston #40389
Jeffrey C. Gaston #40389
Elizabeth S. Marcus #16092
Britney Beall-Eder #64935
Kimberly L. Martinez #40351
Jason C. Hilliard #40856
Caren Jacobs Castle #11790
Barbara Bader #10394
Katharine E. Fisher #39230
Anthony L. Converse #40212
Castle Stawiarski, LLC 999 18TH ST., #2201, DENVER, CO 80202 (303) 865-1400
The attorney above is acting as a debt collector and is attempting to collect a debt. Any information provided may be used for that purpose.
Attorney file #: 10-07484
©Colorado Public Trustees’ Association Revised 12/2009
Published March 17, 24, 31, April 7 and 14, 2011 in The Pagosa Springs SUN.
_________________________________________
COMBINED NOTICE - PUBLICATION
CRS §38-38-103 FORECLOSURE
SALE NO. 2011-007
To Whom It May Concern: This Notice is given with regard to the following described Deed of Trust:
On January 12, 2011, the undersigned Public Trustee caused the Notice of Election and Demand relating to the Deed of Trust described below to be recorded in the County of Archuleta records.
Original Grantor(s): Janice Louise Roberts
Original Beneficiary(ies): Citizens Bank of Pagosa Springs
Current Holder of Evidence of Debt: Wells Fargo Bank, N.A.
Date of Deed of Trust: 12/29/2006
County of Recording: Archuleta
Recording Date of Deed of Trust: 12/29/2006
Recording Reception Number: 20612495
Original Principal Amount: $276,000.00
Outstanding Principal Balance: $275,723.57
Pursuant to CRS §38-38-101(4)(i), you are hereby notified that the covenants of the deed of trust have been violated as follows: failure to pay principal and interest when due together with all other payments provided for in the evidence of debt secured by the deed of trust and other violations thereof.
THE LIEN FORECLOSED MAY NOT BE A FIRST LIEN.
THE PROPERTY DESCRIBED HEREIN IS ALL OF THE PROPERTY CURRENTLY ENCUMBERED BY THE LIEN OF THE DEED OF TRUST.
LOT 489 IN TWINCREEK VILLAGE, ACCORDING TO THE PLAT THEREOF FILED FOR RECORD NOVEMBER 5, 1973 AS RECEPTION NO. 78739.
Also known by street and number as: 348 Twincreek Cir, Pagosa Springs, CO 81147
NOTICE OF SALE
The current holder of the Evidence of Debt secured by the Deed of Trust, described herein, has filed Notice of Election and Demand for sale as provided by law and in said Deed of Trust.
THEREFORE, Notice Is Hereby Given that I will at public auction, at 10:00 A.M. on Thursday, 05/12/2011, at 449 San Juan St., Pagosa Springs, CO 81147, sell to the highest and best bidder for cash, the said real property and all interest of the said Grantor(s), Grantor(s)’ heirs and assigns therein, for the purpose of paying the indebtedness provided in said Evidence of Debt secured by the Deed of Trust, plus attorneys’ fees, the expenses of sale and other items allowed by law, and will issue to the purchaser a Certificate of Purchase, all as provided by law.
First Publication: 3/17/2011
Last Publication: 4/14/2011
Name of Publication: Pagosa Springs Sun
DATE: 01/12/2011
Betty A. Diller, Public Trustee in and for the County of Archuleta, State of Colorado
By: /s/ Betty A. Diller, Public Trustee
The name, address, telephone number and bar registration number of the attorney(s) representing the legal holder of the indebtedness is:
Cristel D. Shepherd #39351
Deanne R. Stodden #33214
Jennifer C. Rogers #34682
Christopher T. Groen #39976
Jeffrey C. Gaston #40389
Jeffrey C. Gaston #40389
Elizabeth S. Marcus #16092
Britney Beall-Eder #64935
Kimberly L. Martinez #40351
Jason C. Hilliard #40856
Caren Jacobs Castle #11790
Barbara Bader #10394
Katharine E. Fisher #39230
Anthony L. Converse #40212
Castle Stawiarski, LLC 999 18TH ST., #2201, DENVER, CO 80202 (303) 865-1400
The attorney above is acting as a debt collector and is attempting to collect a debt. Any information provided may be used for that purpose.
Attorney file #: 10-26679
©Colorado Public Trustees’ Association Revised 12/2009
Published March 17, 24, 31, April 7 and 14, 2011 in The Pagosa Springs SUN.
_________________________________________
COMBINED NOTICE - PUBLICATION
CRS §38-38-103 FORECLOSURE
SALE NO. 2011-006
To Whom It May Concern: This Notice is given with regard to the following described Deed of Trust:
On January 12, 2011, the undersigned Public Trustee caused the Notice of Election and Demand relating to the Deed of Trust described below to be recorded in the County of Archuleta records.
Original Grantor(s): Brendan A. McDermott and Deborah L. Alexus
Original Beneficiary(ies): First Southwest Bank
Current Holder of Evidence of Debt: First Southwest Bank
Date of Deed of Trust: 8/17/2005
County of Recording: Archuleta
Recording Date of Deed of Trust: 8/23/2005
Recording Reception Number: 20508716
Original Principal Amount: $340,793.28
Outstanding Principal Balance: $316,918.06
Pursuant to CRS §38-38-101(4)(i), you are hereby notified that the covenants of the deed of trust have been violated as follows: failure to pay principal and interest when due together with all other payments provided for in the evidence of debt secured by the deed of trust and other violations thereof.
THE LIEN FORECLOSED MAY NOT BE A FIRST LIEN.
THE PROPERTY DESCRIBED HEREIN IS ALL OF THE PROPERTY CURRENTLY ENCUMBERED BY THE LIEN OF THE DEED OF TRUST.
Lot 263 Pagosa Meadows Unit Four, according to the plat thereof recorded June 4, 1973 as Reception No. 77867
Also known by street and number as: 443 Elbert Place, Pagosa Springs, CO 81147
NOTICE OF SALE
The current holder of the Evidence of Debt secured by the Deed of Trust, described herein, has filed Notice of Election and Demand for sale as provided by law and in said Deed of Trust.
THEREFORE, Notice Is Hereby Given that I will at public auction, at 10:00 A.M. on Thursday, 05/12/2011, at 449 San Juan St., Pagosa Springs, CO 81147, sell to the highest and best bidder for cash, the said real property and all interest of the said Grantor(s), Grantor(s)’ heirs and assigns therein, for the purpose of paying the indebtedness provided in said Evidence of Debt secured by the Deed of Trust, plus attorneys’ fees, the expenses of sale and other items allowed by law, and will issue to the purchaser a Certificate of Purchase, all as provided by law.
First Publication: 3/17/2011
Last Publication: 4/14/2011
Name of Publication: Pagosa Springs Sun
DATE: 01/12/2011
Betty A. Diller, Public Trustee in and for the County of Archuleta, State of Colorado
By: /s/ Betty A. Diller, Public Trustee
The name, address, telephone number and bar registration number of the attorney(s) representing the legal holder of the indebtedness is:
Maynes, Bradford, Shipps & Sheftel, LLP Attorneys at Law, 835 East Second Avenue, Suite 123, Durango, CO 81302 (970) 247-1755
The attorney above is acting as a debt collector and is attempting to collect a debt. Any information provided may be used for that purpose.
Attorney file #: McDermott
©Colorado Public Trustees’ Association Revised 12/2009
Published March 17, 24, 31, April 7 and 14, 2011 in The Pagosa Springs SUN.
_________________________________________
COMBINED NOTICE - PUBLICATION
CRS §38-38-103 FORECLOSURE
SALE NO. 2011-009
To Whom It May Concern: This Notice is given with regard to the following described Deed of Trust:
On January 13, 2011, the undersigned Public Trustee caused the Notice of Election and Demand relating to the Deed of Trust described below to be recorded in the County of Archuleta records.
Original Grantor(s): David Harbur and Lorita Harbur
Original Beneficiary(ies): Citizens Bank of Pagosa Springs
Current Holder of Evidence of Debt: Citizens Bank of Pagosa Springs
Date of Deed of Trust: 10/10/2007
County of Recording: Archuleta
Recording Date of Deed of Trust: 10/22/2007
Recording Reception Number: 20709910
Original Principal Amount: $65,917.74
Outstanding Principal Balance: $67,523.24
Pursuant to CRS §38-38-101(4)(i), you are hereby notified that the covenants of the deed of trust have been violated as follows: failure to pay principal and interest when due together with all other payments provided for in the evidence of debt secured by the deed of trust and other violations thereof.
THE LIEN FORECLOSED MAY NOT BE A FIRST LIEN.
THE PROPERTY DESCRIBED HEREIN IS ALL OF THE PROPERTY CURRENTLY ENCUMBERED BY THE LIEN OF THE DEED OF TRUST.
LOT 89, MARTINEZ MOUNTAIN ESTATES, ACCORDING TO THE PLAT THEREOF FILED NOVEMBER 8, 1978, AS RECEPTION NO. 93208, IN THE OFFICE OF THE CLERK AND RECORDER, ARCHULETA COUNTY, COLORADO
Also known by street and number as: 298 Horseshoe Circle, Pagosa Springs, CO 81147
NOTICE OF SALE
The current holder of the Evidence of Debt secured by the Deed of Trust, described herein, has filed Notice of Election and Demand for sale as provided by law and in said Deed of Trust.
THEREFORE, Notice Is Hereby Given that I will at public auction, at 10:00 A.M. on Thursday, 05/12/2011, at 449 San Juan St., Pagosa Springs, CO 81147, sell to the highest and best bidder for cash, the said real property and all interest of the said Grantor(s), Grantor(s)’ heirs and assigns therein, for the purpose of paying the indebtedness provided in said Evidence of Debt secured by the Deed of Trust, plus attorneys’ fees, the expenses of sale and other items allowed by law, and will issue to the purchaser a Certificate of Purchase, all as provided by law.
First Publication: 3/17/2011
Last Publication: 4/14/2011
Name of Publication: Pagosa Springs Sun
DATE: 01/13/2011
Betty A. Diller, Public Trustee in and for the County of Archuleta, State of Colorado
By: /s/ Betty A. Diller, Public Trustee
The name, address, telephone number and bar registration number of the attorney(s) representing the legal holder of the indebtedness is:
William J. Darling ##32929
William J. Darling P O Box 959, Pagosa Springs, CO 81147 (970) 731-4580
The attorney above is acting as a debt collector and is attempting to collect a debt. Any information provided may be used for that purpose.
Attorney file #: CI70-035
©Colorado Public Trustees’ Association Revised 12/2009
Published March 17, 24, 31, April 7 and 14, 2011 in The Pagosa Springs SUN.
_________________________________________
District Court, Archuleta County, State of Colorado
Court Address: PO Box 148, 449 San Juan St.
Pagosa Springs, CO 81147
EAGLE’S LOFT PROPERTY OWNERS ASSOCIATION, INC.
Plaintiffs,
vs.
NATHAN RAMADOSS, LALLI RAMADOSS and All Unknown Persons Who Claim Any Interest In The Subject Matter Of This Action,
Defendants.
Attorney for Plaintiffs:
Larry W. Holthus
PO Box 1737
Pagosa Springs, CO 81147
Phone Number: (970) 264-4196
FAX Number: (970) 264-4197
Atty. Reg. #: 10535
Case Number: 10CV329
SUMMONS BY PUBLICATION
THE PEOPLE OF THE STATE OF COLORADO TO THE ABOVE NAMED DEFENDANTS:
You are hereby summoned and required to appear and defend against the claims of the Complaint filed with the Court in this action, by filing with the Clerk of this Court, an Answer or other response. You are required to file your Answer or other response within thirty (30) days after the date of the last publication. A copy of the Complaint may be obtained from the Clerk of the Court.
If you fail to file your Answer or other response to the Complaint in writing within thirty (30) days after the date of the last publication, judgment by default may be rendered against you by the Court for the relief demanded in the Complaint without further notice.
This is an action to quiet title to:
Unit Number 12, Building Number 12, Unit Week Number 15, in “EAGLE’S LOFT – Phase Two, as Reception No. 122870 and in accordance with and as limited and defined by the Declaration of Individual and/or Interval Ownership, recorded under Reception Number 117700 in Book 200 at Page 834 et seq and amendments and supplements thereto in the Office of the County Clerk and Recorder in and for Archuleta County, Colorado.
Dated this 28TH day of February, 2010.
/s/ Larry W. Holthus
Larry W. Holthus
Published March 17, 24, 31, April 7 and 14, 2011 in The Pagosa Springs SUN.
_________________________________________
DISTRICT COURT
ARCHULETA COUNTY, COLORADO
Court Address: P.O. Box 148, Pagosa Springs, Colorado 81147
Phone Number: (970) 264-5932
Plaintiff(s): ELK RUN PROPERTY OWNERS ASSOCIATION, INC., a Colorado Nonprofit Corporation
Defendant(s): SKY W. GOMER, KENNETH E. LEAKE, JR., VICKIE G. LEAKE, JON CURTIS TRIMBLE, BOBBIE JO TRIMBLE, ELLEN L. HAYNES, ROBERT P. GIVENS, JR., RUDYDELL GIVENS, JULIE A. MATATALL, ROBERT E. HERRICK, PAWNA LYN BLACKHORSE, JAMES M. HERRING, DOROTHY G. HERRING, THOMAS NIEBLER
Attorney or Party Without Attorney:
Andrew D. Craig
Attorney for Plaintiff
700 Main Avenue, Suite G
Durango, Colorado 81301
Phone Number: (970) 385-7756
E-mail:
Fax Number: (970) 375-3279
Atty. Reg. #: 021217
Case Number: 2010 CV 167
SHERIFF’S COMBINED NOTICE OF SALE AND RIGHTS TO CURE AND REDEEM
Under a Judgment in Rem and Decree of Foreclosure entered December 20, 2010, in the above entitled action, I am ordered to sell nine (9) time-share properties, as follows:
Each Property is a time share estate in ELK RUN, a timeshare community, as described in the plat recorded under Reception No. 140480, and the Declaration of Protective Covenants and Interval Ownership for ELK RUN TOWNHOUSES (“Declaration”) recorded under Reception No. 140481, each recorded in the Office of the County Clerk and Recorder in and for Archuleta County, Colorado, and amendments and supplements thereto. Each such time share estate is generally described as follows: From 4:00 P.M. on the first day until 4:00 P.M. on the last day assigned to said Owner during the below described Lot (Unit) Week(s) Number(s) as said Lot (Unit) Week is numbered and defined in the Declaration.
Record Owner: Description of Property Delinquent Judgment
to be Foreclosed*: Assessments: Amount:
SKY W. GOMER Lot (Unit) Week(s) Number(s) 13 $3,804.00 $5,464.56
Lot (Unit) Number 7104
Building Number 001
KENNETH E. LEAKE, Lot (Unit) Week(s) Number(s) 16 $1,049.00 $1,414.22
JR. & VICKIE G. LEAKE Lot (Unit) Number 7107
Building Number 002
JON CURTIS TRIMBLE Lot (Unit) Week(s) Number(s) 35 $1,534.00 $2,068.08
& BOBBIE JO TRIMBLE Lot (Unit) Number 7111
Building Number 003
ELLEN L. HAYNES Lot (Unit) Week(s) Number(s) 37 $1,384.00 $1,865.86
Lot (Unit) Number 7113
Building Number 004
ROBERT P. GIVENS, JR. Lot (Unit) Week(s) Number(s) 13 $1,534.00 $2,068.08
& RUDYDELL GIVENS Lot (Unit) Number 7114
Building Number 004
JULIE A. MATATALL Lot (Unit) Week(s) Number(s) 48 $1,624.00 $2,189.42
Lot (Unit) Number 7115
Building Number 004
ROBERT E. HERRICK & Lot (Unit) Week(s) Number(s) 46 $1,999.00 $2,694.98
PAWNA LYN BLACKHORSE Lot (Unit) Number 7116
Building Number 004
JAMES M. HERRING & Lot (Unit) Week(s) Number(s) 49 $7,789.00 $10,500.85
DOROTHY G. HERRING Lot (Unit) Number 7101
Building Number 01A
THOMAS NIEBLER Lot (Unit) Week(s) Number(s) 05 $1,049.00 $1,414.22
Lot (Unit) Number 7108
Building Number 002
EACH PROPERTY TO BE SOLD AND DESCRIBED HEREIN IS ALL OF THE PROPERTY CURRENTLY ENCUMBERED BY THE LIEN BEING FORECLOSED.
EACH PROPERTY WILL BE SOLD SEPARATELY.
EACH LIEN BEING FORECLOSED MY NOT BE A FIRST LIEN.
The covenants of the Declaration of Protective Covenants and Interval Ownership for ELK RUN TOWNHOUSES, have been violated as follows: failure to pay assessments when the same were due and owing.
NOTICE OF SALE
THEREFORE, NOTICE IS HEREBY GIVEN that I will, at 10:00 A.M., on June 1, 2011, in the Office of the Archuleta County Sheriff, 449 San Juan Street, Pagosa Springs, Colorado, sell to the highest and best bidder for cash, the said real properties described above, and all interest of each said Record Owner and the heirs and assignees of each said Record Owner, for the purpose of paying the associated judgment amount entered herein, and will deliver to each purchaser a Certificate of Purchase, all as provided by law.
First Publication:
Last Publication:
Name of Publication:
NOTICE OF RIGHTS
YOU MAY HAVE AN INTEREST IN ONE OF THE REAL PROPERTIES BEING FORECLOSED, OR HAVE CERTAIN RIGHTS OR SUFFER CERTAIN LIABILITIES PURSUANT TO COLORADO STATUTES AS A RESULT OF SAID FORECLOSURE. YOU MAY HAVE THE RIGHT TO REDEEM SAID REAL PROPERTY OR YOU MAY HAVE THE RIGHT TO CURE A DEFAULT UNDER THE LIEN BEING FORECLOSED.
A NOTICE OF INTENT TO CURE PURSUANT TO §38-38-104, C.R.S., SHALL BE FILED WITH THE SHERIFF AT LEAST FIFTEEN (15) CALENDAR DAYS PRIOR TO THE FIRST SCHEDULED SALE DATE OR ANY DATE TO WHICH THE SALE IS CONTINUED.
A NOTICE OF INTENT TO REDEEM FILED PURSUANT TO §38-38-302, C.R.S., SHALL BE FILED WITH THE SHERIFF NO LATER THAN EIGHT (8) BUSINESS DAYS AFTER THE SALE.
The name, address and telephone number of the attorney representing the holder of the lien being foreclosed are: Andrew D. Craig, Atty Reg. No. 21217, 700 Main Avenue, Suite G, Durango, Colorado 81301; (970) 385-7756.
THIS IS AN ATTEMPT TO COLLECT A DEBT AND ANY INFORMATION OBTAINED MAY BE USED FOR THAT PURPOSE.
This Sheriff’s Notice of Sale is signed February 28, 2011.
PETER L. GONZALEZ
Sheriff, Archuleta County, Colorado
By /s/ Peter L. Gonzalez
Published March 17, 24, 31, April 7 and 14, 2011 in The Pagosa Springs SUN.
_________________________________________
COMBINED NOTICE - PUBLICATION
CRS §38-38-103 FORECLOSURE
SALE NO. 2011-001
To Whom It May Concern: This Notice is given with regard to the following described Deed of Trust:
On January 5, 2011, the undersigned Public Trustee caused the Notice of Election and Demand relating to the Deed of Trust described below to be recorded in the County of Archuleta records.
Original Grantor(s): SANDRA HILTON
Original Beneficiary(ies): MORTGAGE ELECTRONIC REGISTRATION SYSTEMS, INC., ACTING SOLELY AS NOMINEE FOR BANK OF COLORADO
Current Holder of Evidence of Debt: SUN TRUST MORTGAGE, INC.
Date of Deed of Trust: 9/20/2007
County of Recording: Archuleta
Recording Date of Deed of Trust: 9/25/2007
Recording Reception Number: 20708905
Original Principal Amount: $180,000.00
Outstanding Principal Balance: $177,412.93
Pursuant to CRS §38-38-101(4)(i), you are hereby notified that the covenants of the deed of trust have been violated as follows: failure to pay principal and interest when due together with all other payments provided for in the evidence of debt secured by the deed of trust and other violations thereof.
THE LIEN FORECLOSED MAY NOT BE A FIRST LIEN.
THE PROPERTY DESCRIBED HEREIN IS ALL OF THE PROPERTY CURRENTLY ENCUMBERED BY THE LIEN OF THE DEED OF TRUST.
LOT 37 OF BLOCK 6 IN AMENDED ASPEN SPRINGS SUBDIVISION NO. 2, ACCORDING TO THE PLAT THEREOF FILED FOR RECORD JUNE 15, 1971 AS RECEPTION NO. 74503.
Also known by street and number as: 303 BUTTERCUP DRIVE, PAGOSA SPRINGS, CO 81147
NOTICE OF SALE
The current holder of the Evidence of Debt secured by the Deed of Trust, described herein, has filed Notice of Election and Demand for sale as provided by law and in said Deed of Trust.
THEREFORE, Notice Is Hereby Given that I will at public auction, at 10:00 A.M. on Thursday, 05/05/2011, at 449 San Juan St., Pagosa Springs, CO 81147, sell to the highest and best bidder for cash, the said real property and all interest of the said Grantor(s), Grantor(s)’ heirs and assigns therein, for the purpose of paying the indebtedness provided in said Evidence of Debt secured by the Deed of Trust, plus attorneys’ fees, the expenses of sale and other items allowed by law, and will issue to the purchaser a Certificate of Purchase, all as provided by law.
First Publication: 3/10/2011
Last Publication: 4/7/2011
Name of Publication: Pagosa Springs Sun
DATE: 01/05/2011
Betty A. Diller, Public Trustee in and for the County of Archuleta, State of Colorado
By: /s/ Betty A. Diller, Public Trustee
The name, address, telephone number and bar registration number of the attorney(s) representing the legal holder of the indebtedness is:
Aronowitz & Mecklenburg, LLP 1199 Bannock Street, Denver, CO 80204 (303) 813-1177
The attorney above is acting as a debt collector and is attempting to collect a debt. Any information provided may be used for that purpose.
Attorney file #: 1301.00883
©Colorado Public Trustees’ Association Revised 12/2009
Published March 10, 17, 24, 31 and April 7, 2010 in The Pagosa Springs SUN.
_________________________________________
COMBINED NOTICE - PUBLICATION
CRS §38-38-103 FORECLOSURE
SALE NO. 2011-003
To Whom It May Concern: This Notice is given with regard to the following described Deed of Trust:
On January 5, 2011, the undersigned Public Trustee caused the Notice of Election and Demand relating to the Deed of Trust described below to be recorded in the County of Archuleta records.
Original Grantor(s): Timothy J Mcavoy
Original Beneficiary(ies): Franklin Security Bank, FSB
Current Holder of Evidence of Debt: The Bank of New York Mellon FKA The Bank of New York as Trustee for the Certificateholders CWALT, Inc. Alternative Loan Trust 2005-85CB Mortgage Pass-Through Certificates, Series 2005-85CB
Date of Deed of Trust: 12/21/2005
County of Recording: Archuleta
Recording Date of Deed of Trust: 1/30/2006
Recording Reception Number: 20601120
Original Principal Amount: $152,000.00
Outstanding Principal Balance: $142,414.50
Pursuant to CRS §38-38-101(4)(i), you are hereby notified that the covenants of the deed of trust have been violated as follows: failure to pay principal and interest when due together with all other payments provided for in the evidence of debt secured by the deed of trust and other violations thereof.
THE LIEN FORECLOSED MAY NOT BE A FIRST LIEN.
THE PROPERTY DESCRIBED HEREIN IS ALL OF THE PROPERTY CURRENTLY ENCUMBERED BY THE LIEN OF THE DEED OF TRUST.
LOT 795 PAGOSA HIGHLAND ESTATES, ACCORDING TO THE PLAT THEREOF FILED FEBRUARY 7, 1972, AS RECEPTION NO. 75409, IN THE OFFICE OF THE CLERK AND RECORDER, ARCHULETA COUNTY, COLORADO
Also known by street and number as: 394 Monte Vista Drive, Pagosa Springs, CO 81147
NOTICE OF SALE
The current holder of the Evidence of Debt secured by the Deed of Trust, described herein, has filed Notice of Election and Demand for sale as provided by law and in said Deed of Trust.
THEREFORE, Notice Is Hereby Given that I will at public auction, at 10:00 A.M. on Thursday, 05/05/2011, at 449 San Juan St., Pagosa Springs, CO 81147, sell to the highest and best bidder for cash, the said real property and all interest of the said Grantor(s), Grantor(s)’ heirs and assigns therein, for the purpose of paying the indebtedness provided in said Evidence of Debt secured by the Deed of Trust, plus attorneys’ fees, the expenses of sale and other items allowed by law, and will issue to the purchaser a Certificate of Purchase, all as provided by law.
First Publication: 3/10/2011
Last Publication: 4/7/2011
Name of Publication: Pagosa Springs Sun
DATE: 01/05/2011
Betty A. Diller, Public Trustee in and for the County of Archuleta, State of Colorado
By: /s/ Betty A. Diller, Public Trustee
The name, address, telephone number and bar registration number of the attorney(s) representing the legal holder of the indebtedness is:
Cristel D. Shepherd #39351
Deanne R. Stodden #33214
Jennifer C. Rogers #34682
Christopher T. Groen #39976
Jeffrey C. Gaston #40389
Jeffrey C. Gaston #40389
Elizabeth S. Marcus #16092
Britney Beall-Eder #64935
Kimberly L. Martinez #40351
Jason C. Hilliard #40856
Caren Jacobs Castle #11790
Barbara Bader #10394
Katharine E. Fisher #39230
Anthony L. Converse #40212
Castle Stawiarski, LLC 999 18TH ST., #2201, DENVER, CO 80202 (303) 865-1400
The attorney above is acting as a debt collector and is attempting to collect a debt. Any information provided may be used for that purpose.
Attorney file #: 10-26420
©Colorado Public Trustees’ Association Revised 12/2009
Published March 10, 17, 24, 31 and April 7, 2010 in The Pagosa Springs SUN.
_________________________________________
COMBINED NOTICE - PUBLICATION
CRS §38-38-103 FORECLOSURE
SALE NO. 2011-004
To Whom It May Concern: This Notice is given with regard to the following described Deed of Trust:
On January 5, 2011, the undersigned Public Trustee caused the Notice of Election and Demand relating to the Deed of Trust described below to be recorded in the County of Archuleta records.
Original Grantor(s): SANDY HAHN
Original Beneficiary(ies): MORTGAGE ELECTRONIC REGISTRATION SYSTEMS, INC. AS NOMINEE FOR FIRST OHIO BANC & LENDING
Current Holder of Evidence of Debt: ONEWEST BANK, FSB
Date of Deed of Trust: 8/31/2006
County of Recording: Archuleta
Recording Date of Deed of Trust: 9/13/2006
Recording Reception Number: 20608861
Original Principal Amount: $90,000.00
Outstanding Principal Balance: $85,896.39
Pursuant to CRS §38-38-101(4)(i), you are hereby notified that the covenants of the deed of trust have been violated as follows: failure to pay principal and interest when due together with all other payments provided for in the evidence of debt secured by the deed of trust and other violations thereof.
THE LIEN FORECLOSED MAY NOT BE A FIRST LIEN.
THE PROPERTY DESCRIBED HEREIN IS ALL OF THE PROPERTY CURRENTLY ENCUMBERED BY THE LIEN OF THE DEED OF TRUST.
LOTS 20 & 21 IN PAGOSA TRAILS BEING KNOWN AS PARCEL NUMBER 569930201031
Also known by street and number as: 182 SAM HOUSTON AVENUE, PAGOSA SPRINGS, CO 81147
NOTICE OF SALE
The current holder of the Evidence of Debt secured by the Deed of Trust, described herein, has filed Notice of Election and Demand for sale as provided by law and in said Deed of Trust.
THEREFORE, Notice Is Hereby Given that I will at public auction, at 10:00 A.M. on Thursday, 05/05/2011, at 449 San Juan St., Pagosa Springs, CO 81147, sell to the highest and best bidder for cash, the said real property and all interest of the said Grantor(s), Grantor(s)’ heirs and assigns therein, for the purpose of paying the indebtedness provided in said Evidence of Debt secured by the Deed of Trust, plus attorneys’ fees, the expenses of sale and other items allowed by law, and will issue to the purchaser a Certificate of Purchase, all as provided by law.
First Publication: 3/10/2011
Last Publication: 4/7/2011
Name of Publication: Pagosa Springs Sun
DATE: 01/05/2011
Betty A. Diller, Public Trustee in and for the County of Archuleta, State of Colorado
By: /s/ Betty A. Diller, Public Trustee
The name, address, telephone number and bar registration number of the attorney(s) representing the legal holder of the indebtedness is:
Lynn M. Janeway #15592
Janeway Law Firm, P. C. 19201 East Main St., Suite 205, Parker, CO 80134-9092 (303) 706-9990
The attorney above is acting as a debt collector and is attempting to collect a debt. Any information provided may be used for that purpose.
Attorney file #: 11768
©Colorado Public Trustees’ Association Revised 12/2009
Published March 10, 17, 24, 31 and April 7, 2010 in The Pagosa
Springs SUN.
_________________________________________
COMBINED NOTICE - PUBLICATION
CRS §38-38-103 FORECLOSURE
SALE NO. 2011-005
To Whom It May Concern: This Notice is given with regard to the following described Deed of Trust:
On January 5, 2011, the undersigned Public Trustee caused the Notice of Election and Demand relating to the Deed of Trust described below to be recorded in the County of Archuleta records.
Original Grantor(s): Kathy Dale and Larry Dale
Original Beneficiary(ies): Mortgage Electronic Registration Systems, Inc., as nominee for Taylor, Bean & Whitaker Mortgage Corp.
Current Holder of Evidence of Debt: Central Mortgage Company
Date of Deed of Trust: 4/30/2008
County of Recording: Archuleta
Recording Date of Deed of Trust: 5/5/2008
Recording Reception Number: 20803278
Original Principal Amount: $152,000.00
Outstanding Principal Balance: $147,997.89
Pursuant to CRS §38-38-101(4)(i), you are hereby notified that the covenants of the deed of trust have been violated as follows: failure to pay principal and interest when due together with all other payments provided for in the evidence of debt secured by the deed of trust and other violations thereof.
THE LIEN FORECLOSED MAY NOT BE A FIRST LIEN.
THE PROPERTY DESCRIBED HEREIN IS ALL OF THE PROPERTY CURRENTLY ENCUMBERED BY THE LIEN OF THE DEED OF TRUST.
LOT F IN BLOCK 30 OF A REPLAT OF A PORTION OF BLOCK 13, PORTION OF BLOCK 14 AND ALL OF BLOCK 30, ASPEN SPRINGS SUBDIVISION UNIT 4, ACCORDING TO THE PLAT THEREOF FILED FOR RECORD DECEMBER 19, 1991 AS RECEPTION NO. 183859.
Also known by street and number as: 181 West Stollsteimer Road, Pagosa Springs, CO 81147
NOTICE OF SALE
The current holder of the Evidence of Debt secured by the Deed of Trust, described herein, has filed Notice of Election and Demand for sale as provided by law and in said Deed of Trust.
THEREFORE, Notice Is Hereby Given that I will at public auction, at 10:00 A.M. on Thursday, 05/05/2011, at 449 San Juan St., Pagosa Springs, CO 81147, sell to the highest and best bidder for cash, the said real property and all interest of the said Grantor(s), Grantor(s)’ heirs and assigns therein, for the purpose of paying the indebtedness provided in said Evidence of Debt secured by the Deed of Trust, plus attorneys’ fees, the expenses of sale and other items allowed by law, and will issue to the purchaser a Certificate of Purchase, all as provided by law.
First Publication: 3/10/2011
Last Publication: 4/7/2011
Name of Publication: Pagosa Springs Sun
DATE: 01/05/2011
Betty A. Diller, Public Trustee in and for the County of Archuleta, State of Colorado
By: /s/ Betty A. Diller, Public Trustee
The name, address, telephone number and bar registration number of the attorney(s) representing the legal holder of the indebtedness is:
Cristel D. Shepherd #39351
Deanne R. Stodden #33214
Jennifer C. Rogers #34682
Christopher T. Groen #39976
Jeffrey C. Gaston #40389
Jeffrey C. Gaston #40389
Elizabeth S. Marcus #16092
Britney Beall-Eder #64935
Kimberly L. Martinez #40351
Jason C. Hilliard #40856
Caren Jacobs Castle #11790
Barbara Bader #10394
Katharine E. Fisher #39230
Anthony L. Converse #40212
Castle Stawiarski, LLC 999 18TH ST., #2201, DENVER, CO 80202 (303) 865-1400
The attorney above is acting as a debt collector and is attempting to collect a debt. Any information provided may be used for that purpose.
Attorney file #: 10-26547
©Colorado Public Trustees’ Association Revised 12/2009
Published March 10, 17, 24, 31 and April 7, 2010 in The Pagosa Springs SUN.
_________________________________________
District Court, Archuleta County, State of Colorado
Court Address: PO Box 148, 449 San Juan St.
Pagosa Springs, CO 81147
EAGLE’S LOFT PROPERTY OWNERS ASSOCIATION, INC.
Plaintiffs,
vs.
BRIAN ELLIOTT HOGUE and All Unknown Persons Who Claim Any Interest In The Subject Matter Of This Action,
Defendants.
Attorney for Plaintiffs:
Larry W. Holthus
PO Box 1737
Pagosa Springs, CO 81147
Phone Number: (970) 264-4196
FAX Number: (970) 264-4197
Atty. Reg. #: 10535
Case Number: 10CV287
SUMMONS BY PUBLICATION
THE PEOPLE OF THE STATE OF COLORADO TO THE ABOVE NAMED DEFENDANTS:
You are hereby summoned and required to appear and defend against the claims of the Complaint filed with the Court in this action, by filing with the Clerk of this Court, an Answer or other response. You are required to file your Answer or other response within thirty (30) days after the date of the last publication. A copy of the Complaint may be obtained from the Clerk of the Court.
If you fail to file your Answer or other response to the Complaint in writing within thirty (30) days after the date of the last publication, judgment by default may be rendered against you by the Court for the relief demanded in the Complaint without further notice.
This is an action to quiet title to:
Unit Number 51, Building Number 51, Unit Week Number 45, in “EAGLE’S LOFT – Phase IV, as Reception No. 137941 and in accordance with and as limited and defined by the Declaration of Individual and/or Interval Ownership, recorded under Reception Number 117700 in Book 200 at Page 834 et seq and amendments and supplements thereto in the Office of the County Clerk and Recorder in and for Archuleta County, Colorado.
Dated this 25TH day of February, 2010.
/s/ Larry W. Holthus
Larry W. Holthus
Published March 10, 17, 24, 31 and April 7, 2011 in The Pagosa Springs SUN.
_________________________________________
